BID/ BUILD REFURBISHMENT OF COURTROOMS FOR THE NATIONAT COURT OF JUSTICE U.S EMBASSY QUITO, ECUADOR
ID: 19GE5026R0018Type: Presolicitation
Overview

Buyer

STATE, DEPARTMENT OFSTATE, DEPARTMENT OFACQUISITIONS - RPSO FRANKFURTWASHINGTON, DC, 20520, USA

NAICS

Nonresidential Building Construction (2362)

PSC

CONSTRUCTION OF OTHER NON-BUILDING FACILITIES (Y1PZ)

Original Source

https://sam.gov/workspace/contract/opp/fe412255e89f4fdd9f04ade011205990/view
Timeline
    Description

    The Department of State is seeking qualified contractors for the refurbishment of courtrooms at the National Court of Justice (NCJ) located at the U.S. Embassy in Quito, Ecuador. This project, under Solicitation No. 19GE5026R0018, involves the design and construction of two criminal hearing rooms, two witness rooms, a press room, two deliberation rooms, and eight restroom facilities, along with an audio-video control room, with an estimated contract value between $500,000 and $800,000. The refurbishment is crucial for enhancing the functionality and efficiency of judicial proceedings at the NCJ. Interested firms must express their interest in writing to Abdelhakim Dyane at dyanea@state.gov by January 16, 2026, and must meet specific requirements, including English proficiency, Ecuadorian operating permits, and registration in the U.S. System for Award Management (SAM).

    Point(s) of Contact
    Abdelhakim Dyane
    dyanea@state.gov
    Files
    Title
    Posted
    19GE5026R0018-Pre-Solicitation.pdf
    The U.S. Consulate General, Frankfurt, issued a pre-solicitation notice (Solicitation No. 19GE5026R0018) for a Firm Fixed-Price Design-Build Construction Contract in 2026. This contract, managed by the Regional Procurement Support Office in Frankfurt, Germany, seeks complete architect and construction services for the refurbishment of courtrooms at the National Court of Justice (NCJ) in Quito, Ecuador. The project, estimated between $500,000 and $800,000, involves creating two criminal hearing rooms, two witness rooms, a press room, two deliberation rooms, and eight restroom facilities on the NCJ mezzanine floor, including an audio-video control room. Interested companies must express interest in writing to DyaneA@state.gov by January 16, 2026, including specific firm details and completing a checklist. Requirements include English proficiency, Ecuadorian operating permits, and mandatory registration in the U.S. System for Award Management (SAM).
    Similar Opportunities
    DESIGN BUILD CONSTRUCTION SERVICES FOR PRE-FABRICATED CONTAINERS AT GUAYAQUIL PORT, ECUADOR
    State, Department Of
    The Department of State is seeking qualified contractors to provide Design Build Construction Services for the installation of pre-fabricated containers at Guayaquil Port, Ecuador. The project entails comprehensive design, construction, and supervision of high-cube containers that will serve as a kitchen, dining area, dormitories for 12 individuals, an administration office, and storage, along with the integration of utilities and installation of various systems such as air conditioning, communication, CCTV, and fire protection. This Firm Fixed-Price Construction Type Contract is estimated to be valued between $250,000 and $500,000, with interested companies required to express their interest by December 2, 2025, via email to Sarah Pfannkuche at PfannkucheS@state.gov, ensuring they meet specific qualifications including Ecuadorian construction licenses and SAM registration prior to contract award.
    Justification and Approval for Local Guard Force Ecuador Extension
    State, Department Of
    The Department of State is seeking to extend the local guard services contract for the U.S. Mission in Ecuador, emphasizing the critical need for uninterrupted security operations. The extension involves a three-month base period along with fifteen one-month options, aimed at ensuring the safety of U.S. personnel, facilities, and equipment from potential threats and unauthorized access. This local guard service is vital for maintaining a secure environment for the execution of U.S. foreign policy, as any lapse in service could jeopardize mission operations and personnel safety. Interested parties can contact Mohammed N. Haque at HaqueMN@state.gov for further details regarding this opportunity.
    TEGUC - Prefabricated Mezzanine Installation
    State, Department Of
    The U.S. Embassy in Tegucigalpa, Honduras, is seeking a contractor for the design, supply, delivery, and installation of a prefabricated mezzanine system at an INL Warehouse. This project requires compliance with U.S. industrial standards, including OSHA and ANSI, and encompasses all structural components, access features, flooring, safety railings, and necessary base preparation. The contract will be a firm-fixed-price type, with delivery expected within 45 days of award, and quotations are due by January 5, 2026, following a site visit on December 15, 2025. Interested contractors must register in the SAM database and submit their offers electronically, adhering to specified formatting requirements. For further inquiries, contact Edward Ortiz or Clinton Jerez at TguBids@state.gov.
    EUR/Athens - Construction of half Basketball Court for US Embassy, Athens
    State, Department Of
    The U.S. Department of State is soliciting quotations for the construction of a half-size basketball court at the U.S. Government-owned residence in Athens, Greece. The project requires adherence to specific technical specifications, including maintaining the existing substrate under the synthetic turf and using a standard wire fence for the court's perimeter. This construction is significant for enhancing recreational facilities at the embassy residence, promoting well-being among staff and visitors. Quotations must be submitted electronically by 10:00 AM Athens time on December 29, 2025, with inquiries directed to Dresden A. Kalin or Giorgos Dimitrokallis at athprocurement@state.gov. The contract will be a firm fixed-price agreement, with a completion timeline of 45 calendar days post-Notice to Proceed, and liquidated damages of €100.00 per day for unexcused delays.
    Custom Made Furniture
    State, Department Of
    The U.S. Department of State, through the U.S. Embassy in Panama City, is seeking qualified vendors to provide custom-made furniture as outlined in solicitation number 19PM0726Q0003. The procurement includes a variety of furniture pieces such as folding tables, reception cubicles, desks, filing cabinets, and conference tables, all of which must meet specific design and material requirements. This furniture is essential for the operational needs of the embassy and must be delivered to the SENAFRONT Operations Center in Summit, Panama, within 30 days after contract award. Interested parties must submit their offers by email to INLPROCPANAMA@STATE.GOV by 3:00 PM (local time) on January 5, 2026, and are encouraged to direct any questions to Claudia Burke at BURKECC@STATE.GOV by December 22, 2025.
    Justification Notice - 19PM0723P0311 -INTERIOR CLEANING AND EQUIPMENT MAINTENANCE SERVICE
    State, Department Of
    The Department of State is seeking qualified contractors to provide interior cleaning and equipment maintenance services for the U.S. Embassy in Panama City. The procurement aims to ensure a clean and well-maintained environment within the embassy facilities, which is essential for the effective operation of diplomatic activities. Interested parties can reach out to primary contact Johanna Martinez at INLPROCPANAMA@STATE.GOV or by phone at 507-317-5000, or secondary contact Timothy Carpenter at PNMPROCREQ@state.gov, also at 507-317-5000, for further details regarding the opportunity.
    Janitorial Services
    State, Department Of
    The U.S. Department of State is soliciting offers for janitorial services at the U.S. Embassy in Reykjavik, Iceland, under contract number 191C7026Q0002. The procurement involves a firm fixed-price contract for a one-year base period with two additional one-year options, covering comprehensive cleaning services across Embassy facilities totaling 1,891 square meters. This contract is crucial for maintaining a clean and safe environment for embassy operations, and it includes specific requirements for personnel standards, insurance, and compliance with federal regulations. Interested vendors must submit their quotations electronically by January 5, 2026, with a site visit scheduled for December 12, 2025, and clarification requests due by December 15, 2025. For further inquiries, vendors can contact the Reykjavik Contracting Officer at reykjavikco@state.gov or by phone at 354-595-2200.
    Installation of fireproofing insulation at Chief of Mission Residence in Madrid, Spain
    State, Department Of
    The Department of State is seeking contractors for the installation of fireproofing insulation at the Chief of Mission Residence in Madrid, Spain. The project requires compliance with both U.S. and Spanish/European codes, and the contractor will be responsible for providing all necessary managerial, administrative, and labor personnel to complete the work. This installation is crucial for ensuring the safety and compliance of the residence, which serves as an official diplomatic facility. The solicitation is expected to be issued in January 2025, and interested contractors must be registered in the SAM database and possess the required permits to operate in Spain. For further inquiries, potential bidders can contact Jerad S. Tietz at tietzjs@state.gov or Lydia Ruiz at ruizlx@state.gov.
    CCTV Installation
    State, Department Of
    The U.S. Embassy in Nassau, The Bahamas, is seeking proposals for the installation of a CCTV system at a U.S. Government property. The project requires bidders to be technically qualified and financially responsible, meeting specific criteria such as SAM registration, English proficiency, and local licensing, with non-Bahamian companies needing to register to do business in The Bahamas and obtain a Bahamian TIN. This installation is crucial for enhancing security measures and involves supplying all necessary labor, materials, and equipment, while adhering to various federal and international codes and standards. Interested contractors must attend a site visit on December 17, 2025, and submit their proposals by December 29, 2025, with all inquiries directed to Deana Nelson at NelsonDA@state.gov.
    Installation of Fire-rated doors at the Chief of Mission Residence in Madrid, Spain
    State, Department Of
    The Department of State is preparing to solicit bids for the installation of fire-rated doors at the Chief of Mission Residence in Madrid, Spain. The project involves replacing existing doors with certified fire-rated doors, including the installation of fire-resistant hardware, panic bars, door closers, and masonry finishes, while ensuring compliance with both U.S. and Spanish/European codes. This procurement is crucial for enhancing safety standards at the residence, and the government plans to issue the solicitation in January 2026, with a site visit to be scheduled prior to that. Interested contractors must possess the necessary permits to operate in Spain and be registered in the SAM database; for further inquiries, they can contact Jerad S. Tietz at tietzjs@state.gov or Lydia Ruiz at ruizlx@state.gov.