Y1DB--CON 663-CSI-021 Renovation Bldg-100 for IR Lab
ID: 36C26025Q0059Type: Sources Sought
Overview

Buyer

VETERANS AFFAIRS, DEPARTMENT OFVETERANS AFFAIRS, DEPARTMENT OF260-NETWORK CONTRACT OFFICE 20 (36C260)VANCOUVER, WA, 98662, USA

NAICS

Commercial and Institutional Building Construction (236220)

PSC

CONSTRUCTION OF LABORATORIES AND CLINICS (Y1DB)

Original Source

https://sam.gov/opp/7911d8788fec4cc0baa37d56af6d6fea/view
Timeline
    Description

    The Department of Veterans Affairs is seeking qualified contractors to provide construction services for the renovation of Building 100 at the Seattle VA Medical Center, specifically to create an Interventional Radiology (IR) Lab. The project involves the renovation of approximately 762 square feet of existing space, including demolition, electrical work, and the installation of a new Siemens Artis Q machine, with a focus on architectural, structural, mechanical, and electrical updates. This renovation is crucial for enhancing the capabilities of the Radiology Department and ensuring compliance with VHA Technical Information Library standards. Interested parties must respond by 11:00 AM PST on November 22, 2024, by submitting a completed Sources Sought Questionnaire and capability statements to Kenneth Winfield at kenneth.winfield@va.gov and Ty Draszt at ty.draszt@va.gov. The estimated contract value is between $500,000 and $1,000,000, and participation in this process does not guarantee a contract award.

    Point(s) of Contact
    Kenneth WinfieldContract Specialist
    (520) 629-4836
    kenneth.winfield@va.gov
    Files
    Title
    Posted
    36C26025Q0059.docx
    The Department of Veterans Affairs (VA) is issuing a Sources Sought Notice for construction services to renovate Building 100 at the Seattle VA Medical Center for an Interventional Radiology (IR) Lab. This notice is not a request for proposals or quotes but aims to identify capable contractors for the project. The renovation will involve preparing approximately 762 square feet of existing space, including demolition, electrical work, and installation of a new Siemens Artis Q machine. The project encompasses architectural, structural, mechanical, and electrical updates, with an estimated magnitude between $500,000 and $1,000,000. Interested parties must respond by November 22, 2024, including completing a questionnaire and submitting capability statements via email. Engagement in this process does not guarantee involvement in the solicitation or contract award. The VA emphasizes the need for critical coordination, adhering to existing finishes, and compliance with design requirements. More information, including a questionnaire, can be accessed through the provided agency URL. Overall, this notice outlines the VA's intent to evaluate potential sources for this renovation project while ensuring safety and compliance standards are upheld.
    663-CSI-021 SOURCES SOUGHT QUESTIONNAIRE.docx
    The Sources Sought Questionnaire is a document issued by the Department of Veterans Affairs to solicit information from potential contractors regarding their eligibility to participate in a government procurement related to commercial and institutional building construction, identified by NAICS Code 236220. The questionnaire requires firms to disclose their business classifications, including Small Business (SB), HUBZone, and Service Disabled Veteran Owned Small Business (SDVOSB), and emphasizes that proof of Systems for Award Management Registration is essential. Additionally, respondents are invited to identify any risks concerning technical, cost, schedule, or performance issues they foresee with the project. Feedback on previous contracts and possible challenges faced in similar contracts is also requested, underscoring the VA's intention to gather insights for improved procurement practices. Importantly, the document advises against sharing proprietary or sensitive information. This questionnaire serves as a preliminary step in assessing the market and ensuring that the requirements of the project align with the capabilities of small and disadvantaged businesses.
    Attachment 1 - SOURCES SOUGHT QUESTIONNAIRE 663-CSI-021.pdf
    The SOURCES SOUGHT QUESTIONNAIRE is a document aimed at gathering information from potential contractors interested in a government procurement, specifically related to commercial and institutional building construction under NAICS Code 236220. It requests firms to confirm their eligibility for various small business programs, such as HUBZone, 8(a), and Service Disabled Veteran Owned Small Business. The document emphasizes the necessity for firms to provide proof of registration in the System for Award Management (SAM). Respondents are invited to identify potential risks, including technical, cost, schedule, or performance-related concerns, and to offer feedback based on experiences with similar contracts. It specifically instructs against including any proprietary or sensitive information in their responses. This questionnaire serves as a preliminary step in the government contracting process, helping the agency assess market capabilities and risks associated with the upcoming solicitation.
    Lifecycle
    Title
    Type
    Y1DB--CON 663-CSI-021 Renovation Bldg-100 for IR Lab
    Currently viewing
    Sources Sought
    Similar Opportunities
    Y1DB--Radiation Oncology Lab Renovation (Oct)
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking contractors for the renovation of the Radiation Oncology Laboratory at the Hunter Holmes McGuire VA Medical Center in Richmond, Virginia. This project, designated under solicitation number 36C24625B0001, involves comprehensive renovations including demolition, construction, and installation of various systems, with a focus on enhancing safety and operational efficiency within the facility. The contract is set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSBs), with a bid range between $2,000,000 and $5,000,000, and a mandatory performance timeframe of 426 days from the Notice to Proceed. Interested parties must submit their bids by November 21, 2024, at 4:00 PM EST, and can direct inquiries to Contract Specialist Aaron R. Holmes at Aaron.Holmes@va.gov.
    C1DA--AE-NRM 668-25-100 Renovate Bldg2 for Admin Space
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking qualified architect-engineer firms to provide design services for the renovation of Building 2 at the Mann-Grandstaff VA Medical Center in Spokane, Washington. The project aims to convert 3,000 square feet of vacant space into administrative offices, enhancing facility functionality while adhering to ADA standards and improving IT, electrical, and HVAC systems. This renovation is critical for the VA's operational efficiency and is budgeted at an estimated construction cost between $500,000 and $1 million. Interested firms must submit their SF 330 Statement of Qualifications by 12:00 PM (PST) on November 26, 2024, to Contract Specialist Kaycee Benson at kaycee.benson@va.gov, ensuring compliance with the Service-Disabled Veteran-Owned Small Business (SDVOSB) requirements.
    6525--SEP 2024 Consolidation - HTME with Extended Installation Services (Includes Turnkey Services)
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking proposals for the acquisition of High-Tech Medical Equipment (HTME) with extended installation services, including turnkey work, as part of the SEP 2024 Consolidation project. This procurement aims to enhance medical imaging capabilities across various VA facilities, ensuring compliance with federal healthcare standards while improving patient care for approximately 26,000 veterans annually. Interested vendors must submit their proposals by March 12, 2025, adhering to specific technical requirements and pricing guidelines outlined in the Request for Offers (RFO). For further inquiries, potential bidders can contact Contracting Officer Michael J Kuchyak at michael.kuchyak@va.gov.
    Z2DA--Renovate Halls, Walls, Ceilings
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking qualified contractors to provide construction services for the renovation of halls, walls, and ceilings in Building 1 at the Durham VA Medical Center. The project involves comprehensive work including hazardous material remediation, interior finishes, demolition, HVAC, and electrical work, aimed at upgrading outdated infrastructure while ensuring minimal disruption to hospital operations. This initiative underscores the VA's commitment to improving medical facility standards, with an estimated contract value between $2 million and $5 million, exclusively set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB). Interested bidders must submit their proposals by January 16, 2025, following a mandatory site visit scheduled for December 4, 2024; for further inquiries, contact Contract Specialist Alice V Custis at Alice.Custis@va.gov.
    Z1DA--Renovate MICU/SICU 539-20-104
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking contractors for the renovation of the Medical Intensive Care Unit (MICU) and Surgical Intensive Care Unit (SICU) at the Cincinnati VA Medical Center, under project number 539-20-104. This comprehensive renovation project aims to enhance healthcare facilities by upgrading mechanical, plumbing, and fire suppression systems, ensuring compliance with VA standards and improving patient care environments. The contract is specifically set aside for Service Disabled Veteran-Owned Small Businesses, with a construction value estimated between $5 million and $10 million, and proposals are due by December 11, 2024, at 2:30 PM EST. Interested parties can contact Ronald T. Heidemann at Ronald.Heidemann@va.gov for further information.
    C1DZ--652-323 Improve Surgical Access (Construction) (VA-24-00021839)
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is soliciting proposals for the construction project titled "C1DZ--652-323 Improve Surgical Access" at the Richmond VA Medical Center in Virginia. This project aims to enhance surgical operating access by constructing approximately 16,000 square feet of new facilities, including advanced operating rooms and support spaces, with a total estimated cost between $10 million and $20 million. The initiative underscores the VA's commitment to modernizing healthcare infrastructure for veterans, ensuring compliance with federal regulations and safety standards throughout the construction process. Interested contractors, particularly those classified as Service-Disabled Veteran-Owned Small Businesses (SDVOSB), must submit their bids electronically by October 29, 2024, at 12:00 PM EDT, and can direct inquiries to Contract Specialist Arianne De Los Reyes at Arianne.DeLosReyes@va.gov.
    Z1DA--607-22-101 Renovate Inpatient Ward 7B (VA-25-00007172)
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking qualified contractors for the renovation of Inpatient Ward 7B at the William S. Middleton VA Hospital in Madison, Wisconsin, under solicitation number 36C25224B0016. The project, designated as VA Project 607-22-101, has an estimated budget between $5 million and $10 million and is specifically set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB), requiring compliance with federal labor standards and affirmative action regulations. This renovation aims to modernize healthcare facilities to enhance patient care for veterans, ensuring adherence to safety and accessibility standards throughout the construction process. Interested bidders must submit their electronic proposals by 12:00 PM local time on October 11, 2024, with a virtual bid opening scheduled for the same day, and can direct inquiries to Contracting Officer John J Meyers at john.meyers2@va.gov.
    Z2DA--657A4-24-105, Site Prep for Fluoro and Xray, PB
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs, Network Contracting Office 15, is seeking proposals for a construction contract focused on site preparation for Fluoro and X-ray equipment at the John J. Pershing VA Medical Center in Poplar Bluff, MO, and the West Plains Clinic. The project involves replacing existing radiology equipment while ensuring minimal disruption to ongoing medical operations, with a contract duration of 120 calendar days and an estimated construction cost between $500,000 and $1,000,000. This opportunity is set aside for service-disabled veteran-owned small businesses, emphasizing compliance with federal regulations and safety standards throughout the project. Interested contractors must attend a mandatory pre-proposal site visit on November 19, 2024, and submit their proposals by December 12, 2024; for further inquiries, they can contact Contract Specialist Abby Monroe at Abby.Monroe2@va.gov or call 913-758-9916.
    648-22-108 Vancouver CLC Exterior Ramp and Access
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking qualified contractors for the construction of an exterior ramp and access improvements at the Portland VA Healthcare System's Vancouver Campus in Washington. This Sources Sought Notice aims to gather market insights and identify potential businesses capable of executing the project, which includes site preparation, demolition of existing structures, and the construction of the access ramp in compliance with specified designs and regulations. The estimated cost for this project ranges from $500,000 to $1,000,000, and responses from interested contractors are due by November 13, 2024, to the designated Contract Specialist, Colleen Nicholson, at Colleen.nicholson@va.gov. This notice serves as a preliminary step to inform future acquisition strategies and does not constitute a solicitation for bids or proposals.
    Y1DB--Establish Radiation Oncology Program at SLVHCS Design Build - New Orleans
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs (VA) is seeking proposals for the design and construction of a Radiation Oncology Addition at the Southeast Louisiana Veterans Health Care System in New Orleans, Louisiana. This project involves comprehensive design-build services to construct a 22,000 square foot addition, which includes the installation of two linear accelerators and a CT-based simulator, along with necessary renovations and site preparations for displaced staff. The selected contractor will be responsible for conducting field investigations, user interviews, and developing specifications and cost estimates to facilitate the construction project. The anticipated solicitation will be issued as an unrestricted Request for Proposals (RFP) in November 2024, with a contract value expected to range between $20 million and $50 million and a performance period of approximately 670 days following the Notice to Proceed. Interested parties must submit inquiries in writing to the designated VA contacts, Bailey Donato and Jennifer Braaten, via email at bailey.donato@va.gov and jennifer.braaten@va.gov, respectively.