Asbestos Abatement - Edenton NFH, NC
ID: 140FC224Q0058Type: Combined Synopsis/Solicitation
Overview

Buyer

INTERIOR, DEPARTMENT OF THEUS FISH AND WILDLIFE SERVICEFWS, CONSTRUCTION A/E TEAM 2Falls Church, VA, 22041, USA

NAICS

Remediation Services (562910)

PSC

ENVIRONMENTAL SYSTEMS PROTECTION- ENVIRONMENTAL REMEDIATION (F108)

Set Aside

Total Small Business Set-Aside (FAR 19.5) (SBA)

Original Source

https://sam.gov/opp/dbb5b3fda2fe4a25b2047cb7ed4cb58e/view
Timeline
    Description

    The U.S. Fish and Wildlife Service, under the Department of the Interior, is seeking qualified contractors for an asbestos abatement project at the Edenton National Fish Hatchery in North Carolina. The procurement involves a Firm-Fixed Price construction contract aimed at safely removing asbestos-containing materials identified in a recent inspection, which highlighted the presence of friable asbestos in multiple buildings. This project is critical for ensuring compliance with federal regulations and protecting public health during ongoing and future construction activities at the site. Interested contractors must submit their proposals by September 10, 2024, at 11:00 AM Pacific Time, and can direct inquiries to Elvia Arellano at elvia_arellano@fws.gov or (505) 248-6438.

    Point(s) of Contact
    Arellano, Elvia
    (505) 248-6438
    elvia_arellano@fws.gov
    Files
    Title
    Posted
    Edenton_Asbestos_Report.pdf
    The Asbestos Inspection Report for the National Fish Hatchery in Edenton, North Carolina, prepared by OBX Environmental Consultants in April 2019, addresses the presence of asbestos-containing materials (ACM) in three buildings. The inspection, authorized by the US Fish and Wildlife Service, identified friable ACM on the exterior and crawlspaces of Building 4, as well as textured ceiling material in Building 1. A total of 89 samples were collected and analyzed, revealing multiple instances of ACM, including textured ceiling materials, drywall, and floor tiles. The report details specific findings for each building, emphasizing the need for controls during renovation and demolition to prevent environmental and health hazards associated with asbestos exposure. Appendices include sketches, a photo-log, and laboratory reports confirming the presence and analysis of ACM. The document underscores compliance with federal regulations regarding asbestos inspection and management, ultimately aiming to ensure safety for ongoing and future construction activities at the site.
    Provisions_and_Clauses.doc
    The Asbestos Abatement Solicitation No. 140FC224Q0058 is a federal request for proposals aimed at contracting a firm for asbestos removal at the Edenton National Fish Hatchery in North Carolina. It details the requirements for a Firm-Fixed Price Construction contract, emphasizing compliance with established guidelines for insurance, safety, and waste management as mandated by federal law. The document outlines various sections, including project specifications, payment procedures, inspection criteria, and special contract requirements relating to work hours, environmental considerations, and hazardous materials. Contractors must submit a structured payment request through the Invoice Processing Platform (IPP) and comply with Davis-Bacon Wage Rates. The solicitation underscores the need for adherence to the Clean Air Act and relevant environmental laws, including provisions for historical and archaeological preservation. Contractors are further instructed to maintain communication with the designated Contracting Officer and comply with federal regulations throughout the project. Overall, this solicitation represents a structured effort by the federal government to ensure safe and compliant asbestos abatement while engaging qualified contractors for construction projects.
    Sol_140FC224Q0058.pdf
    This document is a solicitation for bids related to a construction project titled "Asbestos Abatement - Administration Building," issued by the U.S. Fish and Wildlife Service located in Falls Church, VA. The contract type is a Firm-Fixed Price, with a budget of less than $25,000. The awarded contractor is required to begin work within 60 days of receiving the Notice to Proceed (NTP), with a total performance period of 60 days. A site visit is encouraged and questions must be submitted in writing by specific deadlines. The submission deadline for quotes is set for September 10, 2024, at 11:00 AM Pacific Time, with proposals assessed based on past performance and pricing. Additional requirements include the provision of performance and payment bonds; however, they are not mandatory for this project. The delivery of services is to occur at the Edenton National Fish Hatchery in Edenton, NC, upon project commencement. The document is structured to guide potential offerors on requirements, deadlines, and evaluation criteria, ensuring compliance with government solicitation processes. This solicitation reflects the government's commitment to addressing environmental concerns through regulated construction practices.
    SOW_Asbestos_Abatement.docx
    The document outlines a Statement of Work (SOW) for asbestos abatement at the Administrative Building of the Edenton National Fish Hatchery in North Carolina. The facility, constructed in 1960, has been found to contain asbestos, requiring abatement in compliance with local, state, and federal regulations. The process will be managed by the U.S. Fish and Wildlife Service (FWS), under the oversight of Engineering Project Manager John Loving. Key details include the responsibilities of the contractor, which encompass obtaining necessary permits, maintaining safety standards as per OSHA regulations, and providing quality control throughout the project. The contractor must also adhere to communication protocols for Requests for Information (RFI) and submittals. Payment structures are outlined, with expectations for monthly payments based on an approved Schedule of Values, emphasizing the need for thorough documentation and approvals to avoid payment delays. The SOW emphasizes cooperation between the government and contractor to ensure efficient project execution while outlining environmental protections and requirements regarding public safety. The document ultimately underscores the importance of safety, adherence to regulatory standards, and effective project management in the successful abatement of asbestos at the site.
    Wage_Determination_NC20240065.pdf
    The document outlines wage determinations for building construction projects in North Carolina, specifically covering Chowan, Dare, Martin, and Washington Counties. It ensures compliance with the Davis-Bacon Act, which mandates minimum wage rates based on federal and state guidelines. The latest determination, number NC20240065, supersedes NC20230065 and stipulates that contracts entered on or after January 30, 2022, must pay a minimum of $17.20 per hour as per Executive Order 14026, while older contracts remain subject to Executive Order 13658, requiring a minimum of $12.90 per hour. It lists various labor classifications, detailing wage rates and fringe benefits for trades such as pipefitters, bricklayers, carpenters, and electricians. The wage determination process is explained, including how classifications can be added post-award and the appeals process if a party disagrees with wage rates. This document serves to inform contractors and workers of their rights and obligations under federal law, ensuring fair compensation within the specified counties and participatory compliance with both federal and state contracting regulations. The wage determinations reflect a broader initiative to protect worker rights and ensure equitable pay in federally funded construction projects.
    Lifecycle
    Title
    Type
    Asbestos Abatement - Edenton NFH, NC
    Currently viewing
    Combined Synopsis/Solicitation
    Similar Opportunities
    Z1DA--631-23-016 Abate Asbestos Renovation 2024
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking contractors for the "Z1DA--631-23-016 Abate Asbestos Renovation 2024" project, which involves the abatement of asbestos in specified areas of the Edward P. Boland VA Medical Center in Leeds, Massachusetts. The project requires comprehensive labor, materials, and permits to ensure compliance with VHA, OSHA, EPA, and state regulations, with work scheduled primarily during off-hours to minimize disruption to hospital operations. This initiative is critical for maintaining a safe healthcare environment while addressing hazardous materials, emphasizing the importance of strict adherence to safety protocols and environmental controls. Interested contractors should contact Chelsea L Rodrigue at chelsea.rodrigue@va.gov for further details, and the project is expected to adhere to the wage determination guidelines outlined for Massachusetts.
    Asbestos Disposal Sault Sainte Marie Project Office
    Active
    Dept Of Defense
    The Department of Defense, specifically the U.S. Army Corps of Engineers (USACE) Detroit District, is soliciting quotes for Professional Industrial Hygiene Services related to the abatement and disposal of asbestos-containing materials at the Sault Sainte Marie Project Office in Michigan. The project involves overseeing the removal of approximately 500 square feet of non-friable asbestos cement board, ensuring compliance with federal and state regulations, and completing all work within a four-week timeframe following contract award. This procurement is classified as Full and Open Competition, with quotes due by November 6, 2024, at 2:00 PM Eastern time, and will be awarded to the lowest-priced responsible offeror that meets the requirements. Interested contractors can reach out to Noah Bruck or Michelle Barr via email for further inquiries.
    Y--TN-DALE HOLLOW NFH-HVAC PURCH & INSTALL
    Active
    Interior, Department Of The
    The U.S. Fish and Wildlife Service is seeking proposals for the purchase and installation of an HVAC system at the Dale Hollow National Fish Hatchery in Celina, Tennessee. The project involves installing a heating and cooling system, specifically a heat pump of 10 tons or larger, in a newly constructed 4,000 square foot facility designed to maintain aquatic species at optimal temperatures. This procurement is crucial for enhancing the hatchery's operational efficiency and supporting endangered species conservation efforts. Interested small businesses must submit their proposals by November 15, 2024, and can direct inquiries to Nicole Johnson at nicolecjohnson@fws.gov. The estimated project budget is below $25,000, and the contract will be awarded based on a best value evaluation considering price, technical capabilities, and past performance.
    F108--Hines - Monitoring Asbestos & Lead Asbestos & Lead Abatement IDIQ 578-24-004
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking qualified contractors for an Indefinite Delivery/Indefinite Quantity (IDIQ) contract to provide asbestos and lead monitoring and testing services at the Hines VA Hospital in Illinois. The contract will involve oversight and inspections during hazardous material abatement operations, requiring contractors to employ certified professionals, including a qualified Industrial Hygienist, and adhere to strict safety regulations and reporting requirements. This procurement is crucial for ensuring a safe environment for staff and patients during construction activities involving hazardous materials. Interested parties should contact Ricky Bond at ricky.bond@va.gov or Kristi Kluck at kristi.kluck3@va.gov for further details, with task orders expected to range from $2,000 to $300,000 over a five-year period, totaling a maximum of $750,000.
    Silvio O.Conte NFW Refuge- Forest Thinning Service
    Active
    Interior, Department Of The
    The U.S. Fish and Wildlife Service, under the Department of the Interior, is seeking proposals for forest thinning services at the Silvio O. Conte National Fish and Wildlife Refuge in Lewis, Essex County, Vermont. The project involves thinning approximately 215 acres of lowland spruce-fir forest to enhance forest health as part of a climate resilience study, with specific guidelines for cutting non-commercial trees while preserving designated reserve areas. This initiative is crucial for promoting sustainable forestry practices and improving biodiversity within public lands. Proposals are due by November 4, 2024, and interested contractors must contact Terrence Anderson at terrenceanderson@fws.gov or call 682-294-0280 for further information.
    C--INDUSTRY DAY SOURCES SOUGHT INTENT TO AWARD
    Active
    Interior, Department Of The
    The U.S. Department of the Interior, specifically the U.S. Fish and Wildlife Service, is hosting an Industry Day event to engage design-build contractors and architects regarding upcoming infrastructure projects at Midway Atoll in the Hawaii Pacific region. The focus of this procurement is on design-build services for critical construction and repair tasks, including the development of inner harbor facilities, seawalls, and the replacement of a failing sewer system, aimed at enhancing the efficiency of infrastructure projects in response to regional disasters. This event, scheduled for November 14, 2024, is informational and not a solicitation for proposals; interested firms must register by November 7, 2024, and can direct inquiries to Tracy Gamble at tracygamble@fws.gov or by phone at 404-679-4055.
    Replace leaking HVAC condenser coil
    Active
    Homeland Security, Department Of
    The Department of Homeland Security, specifically the U.S. Coast Guard, is seeking qualified contractors to replace a leaking HVAC condenser coil assembly at its facility in Pine Bluff, Arkansas. This procurement is designated as a Total Small Business set-aside under NAICS Code 238220, with an estimated construction cost ranging from $25,000 to $100,000. The selected contractor will be responsible for ensuring minimal disruption to operations while adhering to federal safety and procurement standards, including compliance with the Buy American Act. Quotes are due by 12:00 PM CST on November 5, 2024, and must be submitted electronically to Clarence Henshaw Jr. at clarence.henshawjr@uscg.mil. Interested parties are encouraged to inspect the site and direct any questions to the designated Contracting Officer Representative by the specified deadline.
    R428--INDUSTRIAL HYGIENE SERVICES
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is conducting market research for Industrial Hygiene Services at the Charles George VA Medical Center in Asheville, NC. The procurement aims to secure services related to mold, lead, and asbestos sampling and air monitoring, adhering to the latest standards and regulatory guidelines. These services are crucial for maintaining a safe medical environment and ensuring compliance with health regulations. Interested contractors, particularly Service Disabled Veteran Small Businesses, must submit their capability statements, relevant past experience, and at least two references by 12:00 PM EST on November 6, 2024, to the Contracting Officer, Warren A Pennil, at warren.pennil@va.gov.
    CONSTRUCTION HAZMAT & AML RESPONSE IDIQ
    Active
    Interior, Department Of The
    The Department of the Interior, specifically the Bureau of Land Management (BLM), is soliciting proposals for the Construction HAZMAT & AML Response Indefinite Delivery/Indefinite Quantity (IDIQ) contract, aimed at addressing hazardous materials and abandoned mine lands across various Western states. Contractors will be required to perform environmental construction services, including hazardous substance removal actions, site assessments, and compliance with environmental regulations under the Comprehensive Environmental Response, Compensation, and Liability Act (CERCLA). This initiative is critical for restoring ecological integrity and ensuring public safety in areas affected by historical mining activities. Proposals are due by November 11, 2024, with a maximum contract ceiling of $45 million and a minimum task order of $5,000, and interested parties should contact Greetchen Jeremie at gjeremie@blm.gov for further details.
    Z1DA--NYHHS Air Monitoring Services
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is soliciting bids for air monitoring services related to asbestos abatement at multiple facilities within the New York Harbor Healthcare System (NYHHS). The procurement requires comprehensive monitoring and air sampling/testing services, including labor, equipment, supplies, and necessary analyses for projects at the Brooklyn VA Medical Center, Margaret Cochran Corbin VA Campus, and St. Albans Community Living Center. This opportunity is specifically set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB), with a contract value estimated between $25,000 and $100,000, and a performance period of 30 calendar days. Interested contractors must submit their quotes by 4:00 PM EST on November 20, 2024, and can direct inquiries to Contract Specialist Yingjie Yeung at Yingjie.Yeung@va.gov.