J061--ATS Replacement Project
ID: 36C24125Q0371Type: Combined Synopsis/Solicitation
Overview

Buyer

VETERANS AFFAIRS, DEPARTMENT OFVETERANS AFFAIRS, DEPARTMENT OF241-NETWORK CONTRACT OFFICE 01 (36C241)TOGUS, ME, 04330, USA

NAICS

Commercial and Industrial Machinery and Equipment (except Automotive and Electronic) Repair and Maintenance (811310)

PSC

MAINT/REPAIR/REBUILD OF EQUIPMENT- ELECTRIC WIRE AND POWER DISTRIBUTION EQUIPMENT (J061)

Set Aside

Total Small Business Set-Aside (FAR 19.5) (SBA)

Original Source

https://sam.gov/opp/1a7d5a73c9fb40908361a9613902b20b/view
Timeline
    Description

    The Department of Veterans Affairs is seeking proposals from qualified contractors for the replacement of the MRI Automatic Transfer Switch (ATS) at the White River Junction Veterans Affairs Medical Center (VAMC). The project involves the removal of the existing ATS and the installation of a larger, contractor-supplied ATS to ensure proper functionality while minimizing disruption to patient care. This procurement is particularly significant as it aims to enhance critical healthcare infrastructure within a functioning medical facility, adhering to strict compliance and safety standards. Interested veteran-owned small businesses must submit their quotes electronically to Contract Specialist Kenya Mitchell by April 17, 2025, with the project expected to be completed within 45 days of the notice to proceed.

    Point(s) of Contact
    Kenya MitchellContract Specialist
    (860) 666-6951
    Kenya.Mitchell1@va.gov
    Files
    Title
    Posted
    36C24125Q0371.docx
    The Combined Synopsis/Solicitation Notice outlines the Request for Quotation (RFQ) for the replacement of the MRI Automatic Transfer Switch (ATS) at the White River Junction VAMC, issued by the Department of Veterans Affairs. The solicitation, numbered 36C24125Q0371, is set aside for veteran-owned small businesses and seeks a firm-fixed price contract for project completion within 45 days of receiving the notice to proceed. Key tasks involve the removal of the current ATS and installation of a larger, contractor-supplied substitute, ensuring proper functionality and compliance with existing healthcare operations to avoid disruption to patient care. Proposals must adhere to regulatory requirements, including registration in the System for Award Management (SAM), and must be submitted electronically to the designated contact by April 17, 2025. Evaluation of quotes will prioritize best value for the government, with specific emphasis on compliance with veteran-owned business requirements and performance commitments. The project highlights the VA's focus on upgrading critical healthcare infrastructure while maintaining rigorous compliance and safety standards.
    Lifecycle
    Title
    Type
    J061--ATS Replacement Project
    Currently viewing
    Combined Synopsis/Solicitation
    Similar Opportunities
    6525--SEP 2025 Consolidation - HTME with Extended Installation Services (Includes Turnkey Services)
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking proposals for the procurement of high-tech medical equipment (HTME) with extended installation services, specifically for the September 2025 Consolidation project. This opportunity includes turnkey services for various medical imaging systems, such as Radiographic/Fluoroscopic (R/F), Computed Tomography (CT), and Nuclear Medicine SPECT/CT systems, which are essential for enhancing diagnostic capabilities and patient care within VA facilities. Interested vendors must adhere to strict submission guidelines and deadlines, with proposals due by March 11, 2026, and inquiries directed to the contracting officer, Michael J Kuchyak, at michael.kuchyak@va.gov.
    J041--SPS VFD REPLACEMENT 26 WASHINGTON DC VAMC 688-26-1-459-0041
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking quotes for the replacement of Variable Frequency Drives (VFD) at the Washington DC VA Medical Center (VAMC). The project involves replacing two ABB ACH580 VFDs with bypasses, upgrading from existing ACH-550-031A-4 VFDs to ACH-550-045A-4 or equivalent, while ensuring continuous operation of air handlers. This procurement is set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB) under NAICS code 561210, emphasizing the importance of supporting veteran-owned enterprises in facilities support services. Interested contractors must submit their quotes by December 19, 2025, at 10:00 AM EST, and can contact Contracting Officer John Ritter at JOHN.RITTER2@VA.GOV or 843-814-0299 for further details.
    Y1DA--518-22-700 EHRM Infrastructure Upgrades Construction Bedford VAMC
    Veterans Affairs, Department Of
    The Department of Veterans Affairs (VA) is preparing to issue a Request for Proposals (RFP) for the EHRM Infrastructure Upgrades Construction project 518-22-700 at the Bedford VA Medical Center (VAMC) in Bedford, MA. This design-bid-build project aims to address deficiencies and upgrade communications cabling in Telecommunications Rooms (TRs) and the Main Computer Room (MCR) across multiple campus buildings and site infrastructure, including the demolition of existing structures and the construction of a new MCR building. The project is critical for enhancing the telecommunications infrastructure, which includes new Fiber Optic and CAT 6a cabling, Work Area Outlets (WAOs), and various systems such as HVAC, CCTV, and Fire Protection. This total Service-Disabled Veteran-Owned Small Business (SDVOSB) set-aside contract is estimated to be valued between $20,000,000 and $50,000, with a performance period of approximately 730 calendar days, and is expected to be issued in mid-December 2025. Interested parties can direct inquiries to Contract Specialist Dawn N Schydzik at dawn.schydzik@va.gov or by phone at 216-447-8300.
    Y1DA-- CT Scan AC Unit Replacement Brooklyn VAMC
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking a qualified contractor for the CT Scan AC Unit Replacement project at the Veterans Affairs Medical Center located in Brooklyn, NY. This procurement is a 100% Service-Disabled Veteran-Owned Small Business (SDVOSB) set-aside, requiring eligible contractors to be registered and verified with the SBA under NAICS code 236220. The contractor will be responsible for furnishing all labor, materials, and equipment necessary to complete the project within 60 calendar days of receiving the Notice to Proceed, adhering to VA specifications. Interested parties should direct inquiries to Charlie Augustin at Charlie.Augustin@va.gov, with the solicitation anticipated to be issued around December 19, 2025.
    J059--Building 19 SCADA Upgrades
    Veterans Affairs, Department Of
    The Department of Veterans Affairs (VA) is seeking quotations for upgrades to the Supervisory Control and Data Acquisition (SCADA) system in Building 19 at the VA Connecticut Healthcare System in West Haven, CT. The project aims to address failed electrical switching capabilities in the Combined Power and Heating plant, which are critical for restoring generator functionality. This procurement is particularly important as it ensures the reliable operation of essential power systems within the healthcare facility. Interested bidders must be OEM-trained and certified, with a mandatory pre-bid walkthrough scheduled for December 12, 2025, and quotes due by December 18, 2025. For further inquiries, contact Contract Specialist Shawn Lawrence at Shawn.Lawrence@va.gov.
    W023--MRI Trailer Lease Amendment Change of Period of Performance
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking proposals for the lease of a 1.5T Mobile MRI Trailer for the Tomah VA Medical Center in Tomah, Wisconsin. This procurement aims to secure a one-year base lease with four optional one-year extensions, requiring the contractor to provide, install, maintain, and train staff on the MRI unit, which must meet specific technical standards. The leased equipment is crucial for enhancing medical imaging capabilities and patient care within the VA healthcare system. Interested vendors, particularly Service-Disabled Veteran-Owned Small Businesses, must submit their proposals by January 16, 2026, at 12 PM Central Time, and can contact Contract Officer Steven MacDonald at steven.macdonald@va.gov or 414-844-4882 for further information.
    Y1DA--589A6-24-410, Replace MDP Panel Bld 89| EKH
    Veterans Affairs, Department Of
    The Department of Veterans Affairs, through the Network Contracting Office 15, is soliciting proposals for the replacement of the main distribution panel in Building 89 at the Dwight D. Eisenhower VA Medical Center in Leavenworth, Kansas. This project, identified as 589A6-24-410, involves extensive general construction work, including the demolition of existing electrical distribution equipment and the installation of new systems, with a performance period of 310 days. The contract is set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSBC) and is valued between $1,000,000 and $5,000,000, emphasizing the importance of compliance with federal regulations and safety standards. Proposals are due by December 19, 2025, with an additional site visit scheduled for December 4, 2025; interested parties should contact Contracting Officer Tim Parison at timothy.parison@va.gov or 913-946-1140 for further details.
    J041--OR MECH HW CW PUMP REPLACEMENT WASHINGTON DC VAMC
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking proposals for the replacement of two non-potable hot water pumps and two chilled water pumps in the Operating Room Mechanical Room at the Washington DC VA Medical Center. This procurement is a 100% Service-Disabled Veteran-Owned Small Business (SDVOSB) set-aside, requiring contractors to perform demolition, equipment supply and installation, electrical work, controls integration, and training for VA staff. The project is critical for maintaining the operational efficiency of the medical facility's heating and cooling systems, ensuring a safe environment for patients and staff. Proposals are due by December 18, 2025, at 10:00 AM EST, and interested parties should contact Contracting Officer John Ritter at john.ritter2@va.gov or 843-814-0299 for further information.
    Y1DZ--523A4-20-208 Replace Boilers and Upgrade Controls
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking a general contractor for the project titled "Replace Boilers and Upgrade Controls" at the West Roxbury VA Medical Center in Massachusetts. This procurement involves the demolition, modification, and renovation of the existing Central Boiler Plant (Building 8), with an estimated construction magnitude between $50 million and $100 million and a performance period of 943 calendar days. The project is critical for upgrading essential infrastructure to support the medical center's operations. A Request for Proposal (RFP) is expected to be posted around November 21, 2025, and interested contractors must be registered in the System for Award Management (SAM). For further inquiries, contact Contracting Officer Heather Libiszewski-Gallien at Heather.Libiszewski-Gallien@va.gov or by phone at 413-584-4040 ext 6386.
    Z2DA--FY26: NRM (PROJ: 516-CSI-142) BB - Site Prep for Emergency Department CT Scanner Replacement
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking qualified contractors for the "BB ED CT Replacement – BUILDING 100" project at the Bay Pines VA Medical Center, which involves site preparation for the installation of a new CT scanner in the emergency department. The project requires comprehensive construction services, including structural modifications, installation of lead-lined walls, and adherence to various safety and quality standards throughout the construction process. This initiative is critical for enhancing the emergency department's capabilities and ensuring compliance with healthcare regulations. Interested contractors, particularly those certified as Service-Disabled Veteran-Owned Small Businesses (SDVOSB), must submit their offers by January 5, 2026, at 2:00 PM EST, and can direct inquiries to Contract Specialist David M Hernandez at David.Hernandez1@va.gov.