Z2DA--675-22-706A EHRM Infrastructure Upgrades Construction Viera VA Clinic
ID: 36C77625B0004Type: Solicitation
Overview

Buyer

VETERANS AFFAIRS, DEPARTMENT OFVETERANS AFFAIRS, DEPARTMENT OFPCAC HEALTH INFORMATION (36C776)INDEPENDENCE, OH, 44131, USA

NAICS

Commercial and Institutional Building Construction (236220)

PSC

REPAIR OR ALTERATION OF HOSPITALS AND INFIRMARIES (Z2DA)
Timeline
  1. 1
    Posted Dec 18, 2024, 12:00 AM UTC
  2. 2
    Updated Feb 19, 2025, 12:00 AM UTC
  3. 3
    Due Mar 18, 2025, 4:30 PM UTC
Description

The Department of Veterans Affairs is soliciting proposals for the EHRM Infrastructure Upgrades Construction project at the Viera VA Clinic in Florida. This project, valued between $2 million and $5 million, is specifically set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB) and involves comprehensive construction work to modernize the clinic's electronic health record management infrastructure. Key requirements include providing all necessary tools, labor, and materials, with a completion timeline of 455 calendar days post-award, while adhering to strict safety and operational protocols to minimize disruption to ongoing medical services. Interested bidders must submit their offers by the extended deadline of March 18, 2025, and can direct inquiries to Contract Specialist Sharese H McKinney at sharese.mckinney@va.gov.

Point(s) of Contact
Shawn A TaverniaContract Specialist
shawn.tavernia@va.gov
Files
Title
Posted
Feb 19, 2025, 5:07 PM UTC
This document outlines a federal solicitation for a construction project focused on the EHRM Infrastructure Upgrades at the Viera VA Medical Center in Florida, with an estimated value of $2 million to $5 million. The project, set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB), requires bidders to provide all tools, labor, and materials necessary for construction in accordance with the provided specifications and drawings. The completion timeline mandates work to begin within a specified number of calendar days post-award and finish within 455 calendar days. A bid guarantee and performance bonds are required as part of the contract terms, and bidders must comply with various federal regulations, including labor standards and equal opportunity requirements. Technical inquiries must be submitted via email, with a specified deadline for questions. The contract is anticipated to be awarded to the lowest responsible bidder whose proposal aligns with the solicitation's terms, stressing compliance with multiple provisions aimed at ensuring fair labor practices and responsible contracting. The document emphasizes the need for bidders to thoroughly review the requirements, acknowledge any amendments, and participate in a site visit for a comprehensive understanding of the project scope.
Dec 9, 2024, 8:37 PM UTC
The Department of Veterans Affairs (VA) intends to solicit bids for a Firm-Fixed-Price contract focused on the Electronic Health Record Modernization (EHRM) Infrastructure Upgrades at the Viera VA Medical Center in Florida. The project requires a general contractor to prepare the site for construction through demolition, site preparation, and the furnishing of labor and materials in accordance with specified requirements. The solicitation will be a total Service-Disabled Veteran-Owned Small Business (SDVOSB) set-aside, prohibiting offers from non-SDVOSB entities. Project estimates place the construction costs between $2 million and $5 million, with a performance period of approximately 455 days post-notice to proceed. The official invitation for bids is expected to be released in mid-December 2024, following the guidelines in the Federal Acquisition Regulation (FAR) Part 14. All inquiries regarding the solicitation must be made in writing to the specified contact at the VA. This initiative underscores the VA’s commitment to enhancing its facilities and infrastructure in service to veterans.
Feb 19, 2025, 5:07 PM UTC
The document pertains to an amendment for a solicitation related to construction services for the Veterans Affairs (VA) Department, specifically for the Electronic Health Record Modernization (EHRM) Infrastructure Upgrade project at Viera. The amendment extends the deadline for offer submissions and provides additional details regarding the Construction Statement of Work (SOW). The contracting officer, Joseph D. Rossano, outlines that all prior terms remain intact unless altered by this amendment. The document emphasizes the importance of acknowledgment of receipt of the amendment by bidders and outlines procedures for making adjustments to previously submitted offers. This amendment signifies a commitment to ensuring that all bidders have the updated information necessary for compliance and successful proposal submissions, thereby supporting the overall project objectives to modernize VA facilities effectively.
Feb 19, 2025, 5:07 PM UTC
The document pertains to an amendment related to the solicitation number 36C77625B0004, issued by the Department of Veterans Affairs for a project aimed at construction infrastructure upgrades at the Viera VA Multi-Specialty Outpatient Clinic. The amendment modifies the timeline for technical questions, now due by January 21, 2025, at 2:00 PM EST, and provides details for an organized site visit scheduled for January 11, 2025, at 10:00 AM EST. Participants of the site visit should gather at the clinic's main entrance. Additionally, Microsoft Teams information for remote attendance is included, allowing stakeholders to join virtually. This amendment is significant in ensuring that all prospective bidders have the necessary information and clarity on the timelines and site logistics, facilitating a structured approach to the purchasing process in federal contracting related to healthcare infrastructure improvements.
Feb 19, 2025, 5:07 PM UTC
This document is an amendment to a solicitation issued by the Department of Veterans Affairs (VA) for the EHRM Infrastructure Upgrades project in Viera, Florida. The primary purpose of the amendment is to provide updated wage rates and to include the sign-in sheet from a site visit conducted on January 11, 2025. It emphasizes the importance of acknowledging the amendment prior to the specified deadline, outlining the required methods for acknowledgment. The amendment also confirms that all previous terms and conditions remain unchanged, reinforcing the continuity of the contract. This modification aligns with federal contracting regulations, ensuring the most current information is accessible to potential offerors. The inclusion of essential documents like the wage rates and site visit attendance list underscores transparency and proper procedural adherence in the procurement process.
Feb 19, 2025, 5:07 PM UTC
The document serves as an amendment to a previous solicitation issued by the Department of Veterans Affairs regarding a contract related to the EHRM IU Construction project in Viera. The primary purpose of this amendment is to extend the deadline for offers, now set for February 25, 2025, at 12:30 PM EST. It outlines the necessary procedures for offerors to acknowledge the amendment and adhere to the revised timeline. Additionally, the document confirms that except for the changes made in this amendment, all other terms and conditions from the original solicitation remain unchanged. The contracting officer, Joseph D. Rossano, oversees this modification, emphasizing the importance of compliance from bidders while maintaining the integrity of the bidding process. Overall, this amendment illustrates the federal procurement process's procedural aspects, ensuring fairness and transparency in soliciting offers for government contracts.
Feb 19, 2025, 5:07 PM UTC
The document is an amendment issued by the Department of Veterans Affairs (VA), specifically the Program Contracting Activity Central, regarding solicitation number 36C77625B0004. The primary purpose of this amendment is to extend the deadline for submitting offers from the previously set date to March 18, 2025, at 12:30 PM Eastern Daylight Time. Additionally, the amendment includes the provision of updated wage rates for the contractors involved. It clarifies that all terms and conditions of the original solicitation or any previous amendments remain unchanged and in full force, except for the adjustments made in this amendment. The document stresses the importance of acknowledging the receipt of this amendment prior to the specified deadline to avoid the rejection of offers. Overall, this amendment is part of the ongoing procurement process managed by the VA to ensure compliance, transparency, and updated information for contractors participating in federal contracts.
Feb 19, 2025, 5:07 PM UTC
The Department of Veterans Affairs is soliciting proposals for the EHRM Infrastructure Upgrades project (Contract Numbers: 36C24819D0022 & 36C77622N0965), focused on enhancing the electronic health record management infrastructure at Viera Medical Centers. The contract outlines general requirements for contractors, including responsibilities for construction, safety, quality control, and environmental considerations. Key tasks include site preparation, demolition, and installations across various trades such as electrical, plumbing, and HVAC systems. It emphasizes adherence to strict security protocols, project scheduling, coordination with ongoing medical operations, and ensuring minimal disruption during the construction process. Additionally, there are provisions for testing and commissioning new systems, maintaining existing utilities, and complying with sustainability certifications like LEED and Green Globes. The project reflects the VA's commitment to improving healthcare infrastructure while ensuring safety and operational continuity within medical facilities.
Feb 19, 2025, 5:07 PM UTC
The document outlines the specifications and requirements for the EHRM Infrastructure Upgrades at the Viera VA Medical Center in Melbourne, Florida. The project intends to address deficiencies in the existing telecommunication and utility systems, bringing them up to current VA standards. It includes architectural, structural, mechanical, plumbing, and electrical enhancements, ensuring compliance with safety guidelines and construction specifications. Key components of the project involve implementing infection control measures during construction to prevent contamination, isolating HVAC systems, and maintaining negative air pressure in work areas. Contractors must follow detailed phasing notes and coordinate with VA representatives to ensure services remain operational. Additionally, all work must occur during approved hours, with strict adherence to health and safety directives. The project highlights the importance of careful planning, coordination among trades, and adherence to regulations, emphasizing the VA's commitment to modernizing healthcare facilities while ensuring patient and staff safety during upgrades.
The Orlando VA Medical Center's Pre-Construction Risk Assessment (PCRA) outlines safety measures and classifications for construction projects, specifically for the Viera VA Clinic upgrades. This assessment addresses potential risks associated with the construction of two new structures and installation of CAT6A structured cabling. It emphasizes necessary precautions to protect patients, staff, and contractors from hazards linked to construction activities, including dust, noise, and infection risks. The document delineates different activity types, ranging from small-scale to large-scale construction, and specifies corresponding control measures. It highlights the coordination required with adjacent areas to minimize disruptions and outlines the Infection Control Risk Assessment (ICRA) necessary for activities that may pose infection risks. An essential part of the process involves communication with point-of-contacts in affected areas, detailing intervention plans, and ensuring compliance with safety standards like the Life Safety Code. The PCRA serves as a comprehensive framework for planning construction work, ensuring regulatory adherence, and safeguarding health during the project initiation and execution phases.
The document appears to be a compilation of government requests for proposals (RFPs), grants, or related communications, potentially embedded within a larger collection of data yet to be deciphered. The main purpose is likely to solicit funds or proposals for various federal, state, and local initiatives. While the file is heavily damaged and appears to consist mostly of garbled text, specific patterns suggest a focus on topics such as infrastructure projects, environmental assessments, or public safety enhancements, which are common in government RFPs. Details regarding compliance, regulatory standards, and health-related guidelines may also be present, addressing potential risks associated with such projects. In summary, the document serves as an official channel for governmental entities to outline projects requiring financial support or contractor engagement. The emphasis on meticulous compliance, safety protocols, and systematic evaluations resonates with the overarching goals of public service and community welfare, reflecting the government’s commitment to ensuring responsible development and resource allocation.
Feb 19, 2025, 5:07 PM UTC
The document outlines the justification and approval for a construction contract related to the EHRM Infrastructure Upgrades at the Viera VA Medical Center (VAMC) in Florida. The contract is a firm-fixed price arrangement intended for specific construction materials that enhance standardization across the facility. Essential brand name items include Trane HVAC controls, Hirsch physical security access systems, Pelco surveillance cameras, and Cisco network switches, all of which are integral to system compatibility and operational efficiency. The total project cost is projected between $2 million and $5 million. The justification cites 41 USC §3304(a)(1)—Only One Responsible Source—as the rationale for limiting competition to these specific brands, noting that alternate products may result in cost duplication and operational failures. The acquisition process will be competed as a Service-Disabled Veteran-Owned Small-Business set-aside to encourage participation and ensure fair pricing. Market research indicates no competing vendors can offer the necessary integration with existing systems. The overall aim is to ensure compliance, safety, and functionality within the VA's operational framework.
The document outlines the requirements for certification of compliance with limitations on subcontracting for federal contracts awarded to Service-Disabled Veteran-Owned Small Businesses (SDVOSBs) and Veteran-Owned Small Businesses (VOSBs). Under 38 U.S.C. 8127(k)(2), contractors must certify that they will not subcontract more than 85% of the contract amount to non-certified firms. Compliance documentation, such as invoices and subcontract records, may be required for review by the VA to ensure adherence to these limitations. Contractors are also informed about the potential consequences of failing to act in good faith, which could result in referral to the VA Suspension and Debarment Committee, financial penalties, and prosecution. The certification must be signed and submitted with bids, as offers lacking this certification will not be considered. In essence, the document reinforces the importance of compliance with contracting regulations aimed at promoting SDVOSB and VOSB participation while establishing accountability measures within federal contracting processes. These rules form part of broader efforts to ensure fair opportunities for veteran-owned businesses in government contracts, contributing to their economic empowerment and support.
Feb 19, 2025, 5:07 PM UTC
The Viera VA Multi-Specialty Outpatient Clinic is coordinating a site visit for the EHRM Infrastructure Upgrades Construction project, scheduled for Saturday, January 11, 2025, at 10 AM. The visit aims to minimize disruptions to patient care and is arranged to address the limited parking situation. Participants are instructed to gather at the Clinic's main entrance, specifically at the rotunda under the car loop canopy. This organized visit is essential for stakeholders involved in the construction upgrades, allowing for initial assessments and planning in alignment with project goals. Adhering to the project timeline and ensuring effective communication among parties is likely a key focus of the visit to facilitate a smooth upgrade process while prioritizing patient care.
This document is a sign-in sheet for a site visit related to the EHRM Infrastructure Upgrades Construction project at Viera VAMC scheduled for January 11, 2025, at 10:00 AM ET. It lists the names, companies, email addresses, and phone numbers of various attendees from different construction and contracting firms, indicating their interest in participating in the project. The sheet captures contact information to facilitate follow-up communication for the construction project.
Feb 19, 2025, 5:07 PM UTC
The file outlines the construction project for EHRM Infrastructure Upgrades at the Viera VA Clinic. The primary purpose is to modernize the clinic's infrastructure to comply with Electronic Health Records Modernization requirements. The scope includes constructing new telecommunication rooms and adhering to specific architectural guidelines set by the VA. Key requirements stipulate that the contractor must maintain a clean work environment, coordinate with clinic operations to minimize disruptions, and implement rigorous safety measures, including OSHA training for all personnel. The contractor is also responsible for providing regular updates and documentation related to safety and project progress. Additionally, the document emphasizes compliance with environmental regulations and mandates a Pre-Construction Risk Assessment to identify potential hazards. The outlined timeline requires project completion within 455 days, with all work scheduled around clinic operating hours. Overall, this initiative reflects the VA's commitment to enhancing healthcare facilities while ensuring operational safety and regulatory compliance.
Feb 19, 2025, 5:07 PM UTC
The government file pertains to various federal and state RFPs (Requests for Proposals) and grants, detailing procedures and guidelines for project solicitations. The document likely includes eligibility criteria, application processes, and funding distributions aimed at enhancing public services or infrastructure projects. Key topics include the submission requirements for proposals, evaluation criteria used by funding bodies, and compliance regulations that applicants must adhere to. Supporting details may cover deadlines for applications, allowable costs, and documentation necessary for funding consideration. The structure appears to be organized strategically to facilitate easy navigation for prospective applicants, ensuring they understand how to prepare and submit proposals compliant with government standards. Overall, the document serves as a comprehensive guide for organizations seeking government funding to implement projects aimed at public benefit or civic improvement.
Feb 19, 2025, 5:07 PM UTC
The document appears to be a compilation of data related to government RFPs (Request for Proposals), grants, and state/local funding opportunities. Although the specific content is difficult to decipher due to the heavy encoding and corruption, the primary purpose is likely to provide information on available funding initiatives, guidelines for applicants, and compliance requirements. Key ideas may include specific funding programs, eligibility criteria, application processes, deadlines, and conditions for award acceptance. Supporting details could encompass insights into the intended beneficiaries of these programs, such as non-profits, local governments, or businesses working on community-focused projects. In the context of federal and state funding opportunities, this document serves as a critical resource for understanding the landscape of available financial support for projects that align with government priorities and community needs. It offers guidance for potential applicants on navigating the complexities of funding applications and ensuring compliance with government regulations and standards. As a comprehensive reference, the document aims to facilitate access to funding, promote transparency, and encourage the implementation of projects that improve community resources or public services. The overarching goal is to ensure effective use of taxpayer funds by advancing initiatives that yield social, economic, and environmental benefits.
Lifecycle
Title
Type
Similar Opportunities
Y1DA--675-22-701 EHRM Infrastructure Upgrades Construction Lake Baldwin (Orlando)
Buyer not available
The Department of Veterans Affairs is seeking qualified contractors for the construction of EHRM Infrastructure Upgrades at Lake Baldwin in Orlando, Florida. This project, identified by solicitation number 36C77624B0028, falls under the NAICS code 236220, which pertains to commercial and institutional building construction, and is set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB). The initiative is crucial for enhancing the VA's infrastructure to support healthcare services, with a total estimated project value of approximately $36 million based on the bids received. Interested contractors can reach out to Contract Specialist Shawn Tavernia at shawn.tavernia@va.gov or Bridget May at bridget.may@va.gov for further details, as the response deadline will be archived 99 days after the unspecified date of the notice.
Z2DA--503-22-700 | EHRM Infrastructure Upgrades Construction | Altoona, PA |
Buyer not available
The Department of Veterans Affairs is soliciting proposals for the EHRM Infrastructure Upgrades Construction project at the James E. Van Zandt VA Medical Center in Altoona, Pennsylvania. This project, valued between $20 million and $50 million, requires a contractor to perform comprehensive construction tasks, including general construction, mechanical, electrical, and plumbing work, over a performance period of 730 days following the notice to proceed. The procurement is exclusively set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB), emphasizing the importance of utilizing veteran-owned firms in federal contracts. Proposals are due by March 7, 2025, and interested parties should contact Contract Specialist Sherri Mitchell at sherri.mitchell@va.gov for further details.
Y1DZ--516-21-107 EHRM Infrastructure Upgrades Construction Lee County VA Clinic (Cape Coral, FL)
Buyer not available
The Department of Veterans Affairs is preparing to solicit bids for the construction of Electronic Health Record Management (EHRM) Infrastructure Upgrades at the Bay Pines VA Healthcare System in Cape Coral, Florida. This project aims to enhance the IT infrastructure, including the installation of a new fiber optic network, HVAC upgrades, and security system improvements, facilitating the transition to a new EHR platform that will benefit multiple VA healthcare facilities in Lee County. The anticipated contract, valued between $2 million and $5 million, will be a Firm-Fixed-Price award set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB), with bids expected to be advertised in late February 2025. Interested parties can direct inquiries to Contract Specialist Amanda Webster at Amanda.Webster@va.gov or by phone at 216-447-8300.
Y1DA--512-22-710 EHRM Infrastructure Upgrades - Loch Raven MD - Construction (VA-24-00060549) Solicitation
Buyer not available
The Department of Veterans Affairs is soliciting proposals for the construction contract related to the Electronic Health Record Modernization (EHRM) Infrastructure Upgrades at the Loch Raven VA Medical Center in Baltimore, Maryland. This project involves extensive renovations across multiple buildings, including the construction of new telecommunication room additions, hazardous material abatement, and upgrades to the communication infrastructure, with a project budget estimated between $10 million and $20 million. The initiative is particularly significant as it aims to enhance healthcare delivery for veterans by modernizing critical facility infrastructure while adhering to stringent safety and regulatory standards. Interested Service-Disabled Veteran-Owned Small Businesses (SDVOSB) must submit their proposals by February 3, 2025, and can direct inquiries to Contract Specialist Melissa Waddell at Melissa.Waddell@va.gov or (216) 447-8300.
Y1DA--562-22-700 | Construction EHRM Infrastructure Upgrades | Erie, PA | Mihaila/Prather | Samantha/Leslie
Buyer not available
The Department of Veterans Affairs is preparing to solicit proposals for a Firm-Fixed-Price contract aimed at executing EHRM Infrastructure Upgrades at the Erie VA Medical Center in Pennsylvania. This construction project encompasses a wide range of tasks, including general construction, electrical power installation, HVAC upgrades, telecommunications reconfiguration, and enhancements to physical security across multiple campus buildings. The initiative is crucial for improving the infrastructure that supports veteran care, with an estimated project value between $20 million and $50 million and a contract duration of approximately 540 days. Interested contractors, particularly those qualifying as Service-Disabled Veteran-Owned Small Businesses (SDVOSB), should direct inquiries to Contract Specialist Leslie Prather at Leslie.Prather@va.gov or call 216-447-8300, with the solicitation expected to be released around late March to early April 2025.
Y1BG--EHRM Construction Infrastructure Upgrades - 679-20-104 -Tuscaloosa VAMC - CO: Bill Henkel CS: Sadaya Brittian COR: Keyonna Fuller
Buyer not available
The Department of Veterans Affairs (VA) is seeking proposals for the EHRM Construction Infrastructure Upgrades project at the Tuscaloosa VA Medical Center, with the intention of awarding a Firm-Fixed-Price contract. The project encompasses extensive upgrades, including the demolition of the existing Greenhouse Building 101, the construction of a new Data Center Building 151, and enhancements to electrical systems, HVAC, communication networks, and physical security across the campus. This initiative is crucial for improving healthcare infrastructure and operational efficiency at the facility. The solicitation is set as a total Service-Disabled Veteran-Owned Small Business (SDVOSB) Set-Aside, with proposals due by March 14, 2025, and an estimated construction cost ranging from $20 million to $50 million. Interested contractors should direct inquiries in writing to the designated email contacts provided in the solicitation.
Y1DZ--PROJECT 675-23-100, Bid-Build (BB) Renovate Lake Nona Building 2 for Emergency Department and Observation Unit
Buyer not available
The Department of Veterans Affairs is soliciting proposals for the renovation of the Emergency Department and Observation Unit at the Orlando VA Medical Center, identified as Project 675-23-100. This project aims to expand the Emergency Department by creating new treatment rooms and updating HVAC systems, with a contract value estimated between $5 million and $10 million, specifically set aside for certified Service-Disabled Veteran-Owned Small Businesses (SDVOSB). The renovation is critical for enhancing healthcare delivery to veterans while ensuring that patient care remains uninterrupted during construction. Proposals are due by March 10, 2025, and interested contractors must register in the System for Award Management and the U.S. Small Business Administration databases. For further inquiries, contact Contract Specialist Elizabeth Romero at Elizabeth.Romero@va.gov.
Y1DA--EHRM Infrastructure Upgrades Data Center Construction - St. Louis JB - Project 657-21-709JB
Buyer not available
The Department of Veterans Affairs is preparing to solicit bids for the construction of an Electronic Health Record Modernization (EHRM) Data Center at the St. Louis VA Medical Center, designated as Contract 36C77625B0008. This project involves relocating the existing data center and implementing significant infrastructure upgrades, including electrical improvements, HVAC assessments, communication infrastructure, and fire suppression systems. The initiative is part of the VA's commitment to enhancing its IT infrastructure to support healthcare services, with an estimated construction cost between $5 and $10 million. The solicitation is set to be issued in March 2025, and interested Service-Disabled Veteran-Owned Small Businesses (SDVOSB) should direct any inquiries to Contract Specialist Thomas Council at Thomas.Council@va.gov or (216) 447-8300.
Z1DA--NRM-CONST 528-22-704 EHRM NEXTGEN WIFI UPGRADES-BUFFALO
Buyer not available
The Department of Veterans Affairs is soliciting proposals for the EHRM NextGen WiFi Upgrades Project at the Buffalo VA Medical Center, focusing on enhancing the facility's wireless infrastructure. The project entails comprehensive contractor services, including the installation of WiFi access points and associated infrastructure, with an estimated budget ranging from $100,000 to $250,000. This initiative is crucial for modernizing the VA's healthcare delivery systems, ensuring reliable internet access for veterans and staff while adhering to federal construction standards. Interested bidders, specifically Veterans-Owned Small Businesses, must submit their proposals by March 6, 2025, and can contact Contracting Officer Idalia Algarin at Idalia.Algarin@va.gov for further information.
Y1DA--FY25: NRM (PROJ: 673-21-149) BB Convert 6 West to Private Patient Rooms
Buyer not available
The Department of Veterans Affairs is soliciting proposals for the renovation of the 6 West wing at the James A. Haley VA Hospital in Tampa, Florida, to convert the area into private patient rooms. This project involves comprehensive demolition and remodeling, including structural updates, mechanical, electrical, and plumbing work, with a strong emphasis on infection control and safety protocols during construction. The initiative aims to enhance patient privacy and care quality, reflecting the VA's commitment to improving healthcare environments for veterans. The estimated project cost ranges from $5 million to $10 million, and interested Service-Disabled Veteran-Owned Small Businesses (SDVOSBs) must submit their proposals by the extended deadline of March 11, 2025, to the designated contracting specialist, David M. Hernandez, at David.Hernandez1@va.gov.