Z2DA-- 523A5-22-010 Enhanced Kitchen Equipment Site Prep
ID: 36C24124B0032Type: Special Notice
Overview

Buyer

VETERANS AFFAIRS, DEPARTMENT OFVETERANS AFFAIRS, DEPARTMENT OF241-NETWORK CONTRACT OFFICE 01 (36C241)TOGUS, ME, 04330, USA

NAICS

Commercial and Institutional Building Construction (236220)

PSC

REPAIR OR ALTERATION OF HOSPITALS AND INFIRMARIES (Z2DA)
Timeline
    Description

    Presolicitation notice from the Department of Veterans Affairs for the procurement of enhanced kitchen equipment site prep services. This service is typically used to provide all equipment, labor, and materials for Project # 523A5-22-010 Enhanced Kitchen Site Prep at the VA Brockton Campus. The period of performance is 196 calendar days and the project has a magnitude between $500,000.00 and $1,000,000.00. This procurement is 100% set-aside for Service-Disabled Veteran-Owned Small Businesses. Interested offerors must be registered in the System for Award Management (SAM) and SDVOSB firms must be verified by the SBA Veteran Small Business Certification (VetCert). The solicitation will be posted on or about January 3, 2024, and all relevant documents can be accessed on the SAM website under Contract Opportunities.

    Point(s) of Contact
    Scott DoucetteContract Specialist
    (978) 833-6051
    scott.doucette@va.gov
    Files
    Title
    Posted
    Similar Opportunities
    Y1DA--FY25: NRM (PROJ: 573-24-700) DB - Upgrade Electrical System - Kitchen
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking proposals for a design-build project to upgrade the electrical system in the kitchen at the Malcom Randall VA Medical Center in Gainesville, Florida. The project involves the installation of a new 480 Volt 3 Phase Main Distribution Panel to support additional kitchen equipment, with a strong emphasis on safety compliance with VA standards and relevant regulations. This upgrade is crucial for enhancing the facility's capacity to provide quality care to veterans, ensuring minimal disruption to kitchen operations during construction. Proposals are due by December 6, 2024, and interested contractors should contact Contracting Officer Calixte Saintil at Calixte.Saintil@va.gov or 813-940-0323 for further information. The estimated project cost ranges from $500,000 to $1,000,000, and the contract is set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB).
    Z1DA--36C242-25-AP-0222 | 630-25-1-6455-0037 EXPANSION JOINT
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is preparing to solicit bids for the Chill Water Expansion Joint Repair project at the Brooklyn VA Medical Center, with the solicitation number 36C24225Q0115. This procurement is exclusively set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB), which must be registered and verified with the SBA VetCert program and SAM.gov, and are required to perform a minimum of 15% of the construction work. The project is critical for maintaining the operational integrity of the medical facility and must be completed within 10 calendar days following the notice to proceed. Interested contractors should direct inquiries to Contracting Officer Charlie Augustin at Charlie.Augustin@va.gov, with the RFQ expected to be issued on or around November 22, 2024, and responses due by 3 PM Eastern Time on the same day.
    Z2DA--657A4-24-105, Site Prep for Fluoro and Xray, PB
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs, Network Contracting Office 15, is seeking proposals for a construction contract focused on site preparation for Fluoro and X-ray equipment at the John J. Pershing VA Medical Center in Poplar Bluff, MO, and the West Plains Clinic. The project involves replacing existing radiology equipment while ensuring minimal disruption to ongoing medical operations, with a contract duration of 120 calendar days and an estimated construction cost between $500,000 and $1,000,000. This opportunity is set aside for service-disabled veteran-owned small businesses, emphasizing compliance with federal regulations and safety standards throughout the project. Interested contractors must attend a mandatory pre-proposal site visit on November 19, 2024, and submit their proposals by December 12, 2024; for further inquiries, they can contact Contract Specialist Abby Monroe at Abby.Monroe2@va.gov or call 913-758-9916.
    Z1DA--NextGen WiFi Upgrades
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking a qualified general contractor for the NextGen WiFi Upgrades project at the Edith Nourse Rogers Memorial Veterans Hospital in Bedford, MA. The project involves the installation of ethernet cables, conduits, and Wi-Fi access points to enhance the facility's wireless infrastructure, with a focus on improving operational efficiency and patient care. This construction contract, classified under NAICS code 236220, has a budget range of $25,000 to $100,000 and is exclusively set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB). Interested contractors should prepare for the upcoming solicitation, expected to be posted on or about November 22, 2024, and can contact Nicholas Muro at Nicholas.Muro@va.gov for further inquiries.
    Z1DA--Pittsburgh-Butler-Erie Construction MATOC| 646-19-112 UD Emergency Dept Access Reno_MATOC SEED Project |646-19-112
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs, specifically the Network Contract Office 4, is preparing to issue a Request for Proposal (RFP) for the Pittsburgh-Butler-Erie Construction MATOC project, which aims to establish up to 10 Firm Fixed-Price contracts for construction projects valued at a cumulative total of $250 million over a five-year period. The procurement emphasizes a tiered evaluation process prioritizing Service-Disabled Veteran-Owned Small Businesses (SDVOSB), followed by other small business categories, ensuring that veteran-owned enterprises are given preference in the bidding process. Interested contractors must be registered in the System for Award Management (SAM) and verified by the Department of Veterans Affairs at the time of proposal submission, with the solicitation expected to be available around October 23, 2024. For further inquiries, potential bidders can contact Contract Specialist John Mignogna at John.Mignogna@va.gov or by phone at 412-377-9786.
    J073--Kitchen Maintenance & Repair
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking qualified contractors for the maintenance and repair of kitchen equipment at the Louis Stokes Cleveland Department of Veterans Affairs Medical Center. The procurement involves a Request for Quotations (RFQ) for comprehensive kitchen maintenance services, including monthly preventive maintenance and 24/7 emergency support with a response time of four hours. This contract is crucial for ensuring the operational efficiency and health compliance of food service systems that serve veterans. Quotes are due by November 29, 2024, at 3 PM EST, and interested parties can contact Contract Specialist Roman Savino at roman.savino@va.gov for further information.
    Z1DA--630-CSI-120 NY SPECT CT SITE PREP DESIGN BUILD
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking proposals for the design-build project titled "Z1DA--630-CSI-120 NY SPECT CT SITE PREP DESIGN BUILD" at the Veterans Affairs Medical Center in Brooklyn, New York. The project involves providing turnkey services for site preparation to install a new Nuclear Medicine GE SPECT CT, including all necessary labor, materials, and compliance with VA specifications and safety regulations. This initiative is crucial for enhancing healthcare services for veterans, ensuring that the facility meets modern operational and safety standards. Interested service-disabled veteran-owned small businesses (SDVOSB) must submit their proposals by December 4, 2024, with a contract award anticipated by December 31, 2024. For further inquiries, contact Contracting Officer Vladimir Stoyanov at Vladimir.Stoyanov@va.gov or by phone at 718-836-6600 ext 8889.
    Y1DA--VISN 1 Construction MATOC
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs (VA) is preparing to issue a Request for Proposal (RFP) for an Indefinite-Delivery Indefinite-Quantity (IDIQ) Multiple Award Task Order Contract (MATOC) specifically for the VISN 1 New England VA Healthcare System. This contract will encompass a wide range of construction projects, including new constructions, repairs, and renovations across various VA medical facilities located in Connecticut, Maine, Massachusetts, New Hampshire, Rhode Island, and Vermont. The initiative is particularly significant as it is set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSBs), with a maximum overall contract value of $1 billion and individual task orders ranging from $1,000 to $50 million. Interested parties must register in the System for Award Management (SAM) database and submit proposals by December 9, 2024, at 1 PM Eastern Time, with Katherine Gibney serving as the primary contact for further inquiries.
    Z1DA--632-16-101 UPGRADE EMERGENCY GENERATORS - PHASE I
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is seeking qualified contractors for the upgrade of emergency generators at the Brooklyn VA Medical Center in New York. This procurement is specifically aimed at enhancing the facility's power reliability and resilience, which is critical for maintaining operations in emergency situations. The solicitation was set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB) under NAICS Code 236220, emphasizing the government's commitment to supporting veteran-owned enterprises. However, it is important to note that the pre-solicitation notice has been cancelled, and interested parties should reach out to Contract Specialist Lester S. Griffith at Lester.Griffith@va.gov or (914) 737-4400 for further information regarding future opportunities or clarifications.
    Z2DA--Replace Flooring in OR, PACU, and Special Procedures
    Active
    Veterans Affairs, Department Of
    The Department of Veterans Affairs is preparing to issue a Request for Proposal (RFP) for the replacement of flooring in the Operating Room (OR), Post Anesthesia Care Unit (PACU), and Special Procedures areas at the Southern Nevada VA Medical Center in Las Vegas. This project, which is exclusively set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB), aims to enhance the facility's operational environment and is estimated to have a value between $5 million and $10 million. The anticipated duration for project completion is approximately 240 calendar days following the issuance of the Notice to Proceed (NTP). Interested contractors must ensure they are registered in SAM.GOV and SBA's VETCERT prior to submission, and any inquiries should be directed to Contract Specialist David Rovner at David.Rovner@va.gov. The solicitation documents are expected to be available around November 19, 2024.