Z1DA--Renovate MICU/SICU 539-20-104
ID: 36C25025B0001Type: Solicitation
Overview

Buyer

VETERANS AFFAIRS, DEPARTMENT OFVETERANS AFFAIRS, DEPARTMENT OF250-NETWORK CONTRACT OFFICE 10 (36C250)DAYTON, OH, 45428, USA

NAICS

Commercial and Institutional Building Construction (236220)

PSC

MAINTENANCE OF HOSPITALS AND INFIRMARIES (Z1DA)
Timeline
  1. 1
    Posted Oct 8, 2024, 12:00 AM UTC
  2. 2
    Updated Jan 29, 2025, 12:00 AM UTC
  3. 3
    Due Jan 29, 2025, 1:00 PM UTC
Description

The Department of Veterans Affairs is soliciting bids for the renovation of the Medical Intensive Care Unit (MICU) and Surgical Intensive Care Unit (SICU) at the Cincinnati VA Medical Center, under project number 539-20-104. The project encompasses comprehensive construction activities across approximately 11,000 square feet, including upgrades to mechanical, plumbing, and electrical systems, with a focus on enhancing patient care and ensuring compliance with health and safety regulations. This initiative is critical for modernizing healthcare facilities to better serve veterans, particularly in light of deficiencies identified during the COVID-19 pandemic. Interested contractors, particularly Service Disabled Veteran-Owned Small Businesses, must submit their proposals by January 29, 2025, and can direct inquiries to Contract Specialist Ronald T. Heidemann at Ronald.Heidemann@va.gov.

Point(s) of Contact
Ronald T HeidemannContracting-Contract Specialist
Ronald.Heidemann@va.gov
Files
Title
Posted
Oct 17, 2024, 5:53 PM UTC
Oct 17, 2024, 5:53 PM UTC
Jan 30, 2025, 8:04 AM UTC
The document outlines a federal Request for Proposal (RFP) for the Renovation of the Medical Intensive Care Unit (MICU) and Surgical Intensive Care Unit (SICU) at the Cincinnati Veterans Affairs Medical Center. The project involves comprehensive construction activities across approximately 21,600 square feet, including demolition and reconstruction of patient rooms, offices, and support facilities. The Contractor is required to provide all necessary materials, labor, and supervision, and is mandated to complete the work within 430 calendar days after receiving the Notice to Proceed. This solicitation is set aside specifically for Service Disabled Veteran-Owned Small Businesses, with a project budget estimated between $5 and $10 million. Essential bidding requirements include an organized site visit, submission of a bid guarantee, and adherence to wage determinations. Bidders must be registered in the System for Award Management (SAM) and comply with federal regulations regarding subcontracting, safety, and environmental standards. The importance of compliance with various federal programs and regulations, such as affirmative action and the Buy American Act, is emphasized, highlighting the government's commitment to ensuring equal employment opportunities and domestic sourcing in federal contracts.
Sep 23, 2024, 11:32 AM UTC
The Department of Veterans Affairs is soliciting construction services for the “Renovate MICU/SICU” project at the Cincinnati VAMC, with the solicitation number 36C25025B0001. The project has an estimated construction cost between $5,000,000 and $10,000,000 and is specifically set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB). The invitation for bids is expected to be issued around October 8, 2024, and all relevant documents, including specifications and drawings, will be available electronically at no cost. Interested parties should submit requests for the bids based on the actual posting of the solicitation. This initiative underscores the VA's commitment to providing construction projects that support veteran-owned businesses, ensuring compliance with federal contracting regulations. The contracting officer for this project is Ron Heidemann, reachable at the provided contact information.
Jan 30, 2025, 8:04 AM UTC
This government document serves as an amendment to a solicitation issued by the Department of Veterans Affairs, specifically the Network Contracting Office (NCO) 10. The primary purpose of the amendment is to clarify the bid opening date for the associated project, now set for November 8, 2024, at 1:30 PM. The amendment emphasizes that all other terms and conditions of the original solicitation remain unchanged. It outlines procedures for offerors to acknowledge receipt of the amendment, specifying that failure to do so may result in the rejection of their offers. The document highlights the structured nature of government procurement processes, ensuring clarity and compliance with established protocols for contract modifications and solicitations. Overall, it underscores the importance of accurate communication regarding bid dates in government contracting processes.
Jan 30, 2025, 8:04 AM UTC
This document is an amendment relating to solicitation number 36C25025B0001 issued by the Department of Veterans Affairs, Network Contracting Office (NCO) 10. The primary objective of this amendment is to clarify the project's square footage, which is specified as 11,000 square feet. The amendment emphasizes that all other terms and conditions from the original solicitation remain unchanged. Offers from bidders must acknowledge receipt of this amendment by a specified deadline to ensure their proposals are considered. The amendment reflects compliance with federal contracting regulations, maintaining transparency and clarity in the bidding process. The document is signed by Ronald T. Heidemann, the Contracting Officer, indicating formal approval of these modifications.
Jan 30, 2025, 8:04 AM UTC
The document is an amendment to a solicitation issued by the Department of Veterans Affairs, specifically the Network Contracting Office (NCO) 10. Its primary purpose is to extend the deadline for the submission of offers regarding a contract solicitation identified as 36C25025B0001. The new deadline is set for December 11, 2024, at 2:30 PM EST. This extension allows additional time for offerors to prepare their proposals. The amendment requires acknowledgment of receipt from bidders and confirms that, except for the changes specified in this document, all terms and conditions of the original solicitation remain unchanged. The identified contract and modification numbers suggest an ongoing procurement process aimed at fulfilling the VA’s operational requirements. This modification reflects standard practice in government contracting to ensure adequate time for submission and compliance by potential contractors.
Jan 30, 2025, 8:04 AM UTC
This document pertains to an amendment of a solicitation issued by the Department of Veterans Affairs, Network Contracting Office (NCO) 10. The primary purpose of this amendment is to extend the deadline for receipt of offers, changing it to January 10, 2025, at 1:30 PM EST. It outlines the necessary steps for offerors to acknowledge the amendment, highlighting that failure to do so may result in the rejection of their offers. The amendment also affirms that other terms and conditions of the original solicitation remain unchanged and in full effect. The document serves as an administrative modification to the contract and specifies that all amended details are required to be respected by the contractors involved. This action is part of the broader scope of government procurement processes seeking to ensure that contractors have a fair opportunity to submit their bids within the newly established timeframe.
Jan 30, 2025, 8:04 AM UTC
This document serves as an amendment to a federal solicitation from the Department of Veterans Affairs, specifically the Network Contracting Office (NCO) 10. The primary purpose of the amendment is to extend the bid opening date for the solicitation identified as 36C25025B0001. The new deadline is set for February 14, 2025, at 1:30 PM EST. The amendment outlines the required procedures for bidders to acknowledge receipt, which can be done in multiple ways including returning copies of the amendment or including acknowledgment in their submitted offers. The document also retains all previous terms and conditions from the original solicitation, ensuring continuity in the bidding process. Overall, this amendment effectively communicates the extension of the deadline while providing clear instructions to participating contractors and maintaining the integrity of the initial solicitation framework.
Jan 30, 2025, 8:04 AM UTC
This document serves as an amendment to solicitation number 36C25025B0001 issued by the Department of Veterans Affairs, Network Contracting Office (NCO) 10. The amendment extends the deadline for receipt of offers to January 29, 2025, at 08:00 EST. Additionally, it announces the cancellation of the solicitation in its entirety. The document outlines necessary actions for bidders to acknowledge the amendment, which includes extending the submission deadline and provides instructions for changing any previously submitted offers. The contracting officer, Ronald T. Heidemann, is responsible for this amendment, indicating adherence to the formal procedures stipulated in federal contracting regulations. The document emphasizes the importance of acknowledgment to ensure bid receptiveness, underscoring compliance with procurement practices.
Jan 30, 2025, 8:04 AM UTC
The document appears to be corrupted or consists of non-readable content, making it impossible to ascertain the main topic or key ideas. It does not present any coherent structure or discernible information pertaining to federal RFPs, grants, or state/local requests. Typically, such documents would include details such as objectives, funding opportunities, and eligibility criteria for prospective applicants. However, due to the unreadable nature of the text, a comprehensive summary cannot be constructed based on the provided content. Further analysis cannot be performed without accessible and relevant information.
Jan 30, 2025, 8:04 AM UTC
The document outlines the Renovation Project for the Medical Intensive Care Unit/Surgical Intensive Care Unit (MICU/SICU) at the Veterans Affairs Medical Center in Cincinnati, Ohio. It details the requirements for contractors, including safety protocols, project management, construction specifications, and security measures. The project involves comprehensive renovations, including general construction, plumbing, mechanical, electrical work, and alterations, to be completed within 430 calendar days after receiving the Notice to Proceed. The document is organized into multiple sections, covering general requirements, demolition, existing conditions, specialized equipment, and various construction divisions such as plumbing, HVAC, electrical, and communications systems. It emphasizes the necessity for contractors to comply with Veterans Affairs security protocols and maintain continuous operations of the Medical Center during renovations. Moreover, the document stresses the need for proper disposal of hazardous materials, thorough site surveys, utility maintenance, and coordination with existing medical services throughout the renovation process. The emphasis on adherence to safety requirements and environmental controls reflects the government's commitment to ensuring the integrity and functionality of essential healthcare facilities while modernizing them to meet current standards.
The document outlines the renovation plans for the Medical Intensive Care Unit (MICU) and Surgical Intensive Care Unit (SICU) at the Department of Veterans Affairs Medical Center in Cincinnati, Ohio. The project involves extensive construction and demolition across multiple floors, ensuring compliance with the latest safety codes, such as the NFPA 101 Life Safety Code and the International Building Code. Specific operations include the removal of existing structures, installation of new medical equipment, and improvements to mechanical systems, all while maintaining operational safety and functionality. Key construction notes highlight the necessity for the contractor to verify dimensions, provide fire-retardant materials, and ensure that all work meets specified codes and standards. Safety measures, including managing contractor access and addressing infection control protocols, are emphasized throughout the plans. The renovation aims to enhance patient care facilities, promoting better healthcare delivery while adhering to a rigorous timeline and budget. Overall, the document serves as a comprehensive blueprint for executing the renovation with a focus on safety, quality, and regulatory compliance.
The document outlines the renovation project for the Medical Intensive Care Unit/Surgical Intensive Care Unit (MICU/SICU) at a Veterans Affairs facility in Cincinnati, Ohio. The project includes comprehensive work on mechanical, plumbing, and electrical systems to upgrade the infrastructure. Key aspects of the renovation involve the extension and replacement of existing fixtures, coordination of electrical components, and ensuring all plumbing is compliant with VA standards. Additionally, the plans specify a negative pressure environment in certain areas, important for health and safety regulations. This project requires meticulous planning and adherence to construction timelines and coordination with other ongoing works to minimize service disruption. General instructions also emphasize safety protocols, including infection control and maintaining existing services while expanding the facility's capabilities. The initiative demonstrates the VA's commitment to enhancing healthcare environments, catered to patient needs and professional standards for veteran care.
Jan 30, 2025, 8:04 AM UTC
The document appears to be a corrupted or improperly formatted file and does not convey any coherent information regarding government requests for proposals (RFPs), federal grants, or state/local RFPs. It contains numerous unreadable characters and symbols, suggesting a failure in data extraction or conversion process. Consequently, the main topic or purpose cannot be discerned, and no key ideas or supporting details can be identified. Given the nature of RFPs and grants, one would expect content related to funding opportunities, project proposals, eligibility criteria, application processes, and evaluation metrics. However, due to the corrupted nature of the file, this essential information is not available. A thorough analysis cannot be conducted as the document lacks meaningful content. Further attempts to retrieve the original data or context are necessary to fulfill the requirements of summarization and analysis concerning government grants and RFPs.
Jan 30, 2025, 8:04 AM UTC
The Department of Veterans Affairs is seeking approval for a series of sole-source contracts to renovate the Medical Intensive Care Unit (MICU) and Surgical Intensive Care Unit (SICU) at the Cincinnati VA Medical Center. The renovation, prompted by deficiencies identified during the COVID-19 pandemic, aims to enhance patient care and ensure pandemic preparedness by redesigning approximately 11,000 square feet of space. Key components of the project include installing new mechanical, electrical, and plumbing systems, a HEPA filtration system, and various specialized medical equipment such as Arjo Patient Lifts, Ascom Nurse Call Systems, and Honeywell fire alarms. The justification for sole-source contracts emphasizes the necessity for uniformity in patient care equipment and systems for operational efficiency and safety. The contracts would ensure integration with existing infrastructure, minimizing the risks of interoperability issues. Each supplier was selected based on their unique qualifications, and necessary market research was conducted to verify the availability of products from Service-Disabled Veteran-Owned Businesses. The process highlights the VA's commitment to maximizing patient safety while modernizing healthcare facilities efficiently.
Jan 30, 2025, 8:04 AM UTC
The document is a Request for Information (RFI) related to the renovation project of the Medical Intensive Care Unit/Surgical Intensive Care Unit (MICU/SICU) at the Cincinnati VA Medical Center. It is articulated under project number 539-20-104 and is organized by the Department of Veterans Affairs, specifically the Network Contracting Office (NCO) 10, led by Contract Specialist Ronald T. Heidemann. The RFI outlines procedures for potential contractors to seek clarifications regarding the solicitation. Contractors must review all relevant documents thoroughly before submitting inquiries and must explicitly cite the section numbers of the specifications or drawings connected to their questions. This requirement is critical to ensure timely and effective responses from the Government. The document emphasizes the importance of compliance with these guidelines, as failure to follow them may delay the Government's ability to provide necessary information. This RFI serves as a formal communication tool to prepare for the subsequent bidding process associated with the renovation project, highlighting the Government’s effort to maintain transparency and facilitate contractor engagement in improving Veteran healthcare facilities.
Jan 30, 2025, 8:04 AM UTC
The "Pre-Award Contractor Safety and Environmental Record Evaluation Form" is a document designated for Solicitation No. 36C25024B0075 that evaluates contractor safety performance and compliance with Occupational Safety and Health Administration (OSHA) regulations. It requires contractors to provide information from their OSHA 300 Forms for the years 2021, 2022, and 2023, including the number of man hours worked, cases involving workplace incidents, and the Days Away, Restricted, or Transferred (DART) rate. Contractors must disclose any serious OSHA violations from the past three years and provide their company’s Insurance Experience Modification Rate (EMR). The form also requests the NAICS code pertinent to the acquisition, specifically 238220. This evaluation is essential for ensuring that contractors meet safety standards and adhere to regulations, which is a critical component of the federal procurement process. Overall, the document aims to promote safe work environments and accountability among contractors bidding for government projects, ensuring compliance with established safety standards prior to contract awards.
Oct 17, 2024, 5:53 PM UTC
Oct 17, 2024, 5:53 PM UTC
Oct 17, 2024, 5:53 PM UTC
Oct 17, 2024, 5:53 PM UTC
Oct 17, 2024, 5:53 PM UTC
Oct 17, 2024, 5:53 PM UTC
Oct 17, 2024, 5:53 PM UTC
Oct 17, 2024, 5:53 PM UTC
Oct 17, 2024, 5:53 PM UTC
Lifecycle
Title
Type
Solicitation
Presolicitation
Similar Opportunities
Z1DA--ICU Renovation VA Medical Center San Francisco Project 662-23-101
Buyer not available
The Department of Veterans Affairs is seeking a qualified General Contractor for the renovation of the Intensive Care Unit (ICU) at the San Francisco VA Medical Center, designated as Project 662-23-101. The project aims to modernize the ICU to meet Airborne Infection Isolation Standards, creating a facility with 10 patient rooms, expandable to 12, while ensuring minimal disruption to ongoing hospital operations. This renovation is critical for enhancing healthcare delivery to veterans and involves extensive construction work on the 3rd floor of Building 203, with a completion timeline of 420 days post-Notice to Proceed. Interested contractors, particularly Service-Disabled Veteran-Owned Small Businesses (SDVOSBs), should contact Contract Specialist Christopher Whipple at christopher.whipple@va.gov, with proposals due by the specified deadline and a project budget estimated between $10 million and $20 million.
Z2DZ--Renovate Primary Care 538-24-100 - Construction - VAMC Chillicothe
Buyer not available
The Department of Veterans Affairs (VA) is seeking qualified Service-Disabled Veteran-Owned Small Businesses (SDVOSB) for the renovation of the Primary Care facilities at the Chillicothe VA Medical Center in Ohio, under project number 538-24-100. This project encompasses approximately 19,084 square feet of renovations aimed at enhancing the Primary Care Department in alignment with the Patient Aligned Care Team (PACT) model, including multi-phase construction to maintain operational continuity, upgrades to security systems, HVAC improvements, and the installation of elevators. The project is significant for improving healthcare delivery to veterans and must adhere to strict infection control and risk assessment guidelines, with an estimated duration of 910 calendar days from the Notice to Proceed. Interested parties should register on SAM.gov for updates, as solicitation documents are expected to be available by April 15, 2025, and all inquiries should be directed to Contract Specialist Jeremy Nee at jeremy.nee@va.gov.
Z1DA--556-23-101: Renovate CLC Building 134-2C
Buyer not available
The Department of Veterans Affairs is seeking qualified contractors to renovate Building 134-2C at the Captain James A. Lovell Federal Health Care Center in North Chicago, Illinois, under Project Number 556-23-101. The renovation involves comprehensive construction work, including selective demolition, installation of new HVAC systems, and ensuring compliance with health and safety standards, with a total area of approximately 12,590 square feet. This project is crucial for enhancing healthcare infrastructure to support veterans, ensuring a safe and functional environment for patient care. Interested contractors, particularly Service-Disabled Veteran-Owned Small Businesses (SDVOSBs), must submit their bids by April 11, 2025, at 10:00 AM CDT, and can direct inquiries to Contract Specialist Hudell D Ballen at Hudell.Ballen@va.gov.
Renovate Interior Corridors of Building 1, Floors 2 & 3
Buyer not available
The Department of Veterans Affairs is seeking qualified contractors to renovate the interior corridors of Building 1, Floors 2 and 3 at the Miami VA Medical Center. The project, estimated to cost between $5 million and $10 million, involves comprehensive renovations including the replacement of walls, floors, and ceilings, as well as updates to lighting and utility systems, with necessary asbestos abatement. This initiative is specifically set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB), highlighting the VA's commitment to supporting veteran-owned enterprises while ensuring compliance with federal regulations. Interested contractors must submit their bids by the end of March 2025 and are encouraged to contact Jean O. Pierre at Jean.Pierre1@va.gov for further details.
Renovate Interior Corridors of Building 1, Floors 2 & 3
Buyer not available
The Department of Veterans Affairs is seeking qualified contractors to renovate the interior corridors of Building 1, Floors 2 and 3, at the Miami VA Healthcare System. This project, identified as number 546-23-112, involves significant updates to the facility, including addressing safety concerns related to asbestos and lead paint, as outlined in the accompanying environmental reports and amendments. The renovation is crucial for maintaining compliance with health and safety standards while enhancing the environment for veterans and staff. Interested parties must submit their proposals by April 4, 2025, at 11 AM EST, and should direct inquiries to Jean O. Pierre at Jean.Pierre1@va.gov or Aldwyn Singleton at aldwyn.singleton@va.gov.
Y1DA-- Improve Patient Privacy 4B Project# 652-14-106
Buyer not available
The Department of Veterans Affairs is seeking qualified contractors for the "Improve Patient Privacy 4B" project at the Richmond VA Medical Center, designated as Project Number 652-14-106. This procurement involves extensive renovations to enhance patient privacy, including the construction of 21 patient rooms and supporting spaces, with a contract value estimated between $5 million and $10 million. The project is a 100% Service-Disabled Veteran-Owned Small Business (SDVOSB) set-aside, emphasizing the importance of veteran-owned enterprises in federal contracting. Interested bidders must submit their proposals by April 22, 2025, with the bid opening scheduled for April 23, 2025. For further inquiries, potential offerors can contact Contract Specialist Denise Morman at Denise.Morman@va.gov.
Z1DA--Renovate Audiology 515-23-101
Buyer not available
The Department of Veterans Affairs is soliciting proposals for the renovation of the Audiology department at the Battle Creek VA Medical Center, designated as Project 515-23-101. The project aims to engage a contractor to perform comprehensive renovations across approximately 6,045 square feet in two buildings, with a total contract budget estimated between $5 million and $10 million and a completion timeline of 500 calendar days post-award. This procurement is exclusively set aside for Service-Disabled Veteran-Owned Small Businesses, emphasizing the importance of compliance with federal labor standards and safety regulations throughout the construction process. Interested contractors should contact Contract Specialist Terrance Deininger at terrance.deininger@va.gov for further details and ensure their proposals are submitted by the specified deadline.
Renovate PM Shop and Replace Aluminum Canopy Roof Section
Buyer not available
The Department of Veterans Affairs is seeking qualified contractors for the renovation of the Preventive Maintenance (PM) shop and the replacement of the aluminum canopy roof at the Miami VA Healthcare System. The project, identified as Project Number 546-22-106, involves significant construction activities, including the installation of a new 5,000 square foot hurricane-rated canopy, a 3,000-pound capacity equipment lift, and various site improvements such as a chain-link fence and drainage systems. This procurement is particularly important as it aims to enhance the infrastructure supporting veteran care while providing opportunities for certified Service-Disabled Veteran-Owned Small Businesses (SDVOSB). Interested contractors must submit their proposals by April 14, 2025, and are encouraged to contact Ana R Vazquez at ana.vazquez2@va.gov or Aldwyn Singleton at aldwyn.singleton@va.gov for further information. The estimated project cost ranges from $1 million to $5 million, with a performance period of 200 calendar days following the Notice to Proceed.
Y1DA--652-323 | Construct Improve Surgical Access | Richmond, VA
Buyer not available
The Department of Veterans Affairs (VA) is seeking potential contractors for a project at the H.H. McGuire VA Medical Center in Richmond, VA, aimed at constructing approximately 16,000 square feet of modern surgical facilities, including advanced operating rooms and an HVAC system. This project is critical for enhancing surgical access and accommodating complex procedures, such as robotic surgery, by expanding existing facilities to meet contemporary healthcare standards. The procurement will utilize a competitive, firm-fixed-price contract approach, with an estimated contract value between $10 million and $20 million, and responses are due by April 14, 2024, at 2:00 PM ET. Interested contractors should submit a capabilities statement electronically, detailing their experience and qualifications, to the primary contact, Amy Graham, at amy.graham@va.gov.
Y1DA--509-23-101 Renovate Public Bathroom, Improve Patient Safety
Buyer not available
The Department of Veterans Affairs is soliciting proposals for the renovation of public bathrooms at the Augusta VA Medical Center, aimed at improving patient safety and facility functionality. This construction project, designated as Project Number 509-23-101, involves comprehensive upgrades across seven floors, including plumbing, lighting, and finishes, while adhering to strict safety and accessibility standards. The contract, valued between $1 million and $5 million, is set aside for Service Disabled Veteran-Owned Small Businesses (SDVOSB), with proposals due by April 18, 2025, at 2:00 PM EST. Interested contractors are encouraged to attend a mandatory site visit on March 4, 2025, and should direct inquiries to Contract Specialist Pamela R Moffitt at pamela.moffitt@va.gov.