Z1DA--Repair Parking Garage Tendon 757-24-204 - Construction - VAACC Columbus
ID: 36C25026B0014Amend0001Type: Solicitation
Overview

Buyer

VETERANS AFFAIRS, DEPARTMENT OFVETERANS AFFAIRS, DEPARTMENT OF250-NETWORK CONTRACT OFFICE 10 (36C250)DAYTON, OH, 45428, USA

NAICS

Commercial and Institutional Building Construction (236220)

PSC

MAINTENANCE OF HOSPITALS AND INFIRMARIES (Z1DA)

Set Aside

Service-Disabled Veteran-Owned Small Business Set Aside (SDVOSBC)

Original Source

https://sam.gov/workspace/contract/opp/7eeab4c12235489fa2d752a10fd09d32/view
Timeline
    Description

    The Department of Veterans Affairs is soliciting bids for the repair of the parking garage tendon at the Columbus VA Medical Center under project number 757-24-204. This construction project involves the repair and restressing of damaged beam tendons, requiring adherence to VA Master Specifications, detailed drawings, and a comprehensive project management plan that includes a Critical Path Method (CPM) schedule and strict security protocols to minimize disruption to the Medical Center's operations. The bid opening is scheduled for December 22, 2025, at 1 PM EST, and interested contractors can obtain further details by contacting Contracting Officer Stanley Burdine at stanley.burdine@va.gov or by phone at 614-388-7827.

    Point(s) of Contact
    Stanley BurdineContracting Officer
    (614) 388-7827
    stanley.burdine@va.gov
    Files
    Title
    Posted
    S02. 757-24-204 - 100_BD_Combined _Specs.pdf
    The Columbus VAMC VA Project 757-24-204 outlines the specifications for the Parking Garage Tendon Repair Design, due by July 18, 2025. This project involves the repair and restressing of damaged beam tendons. Key requirements include adherence to VA Master Specifications, detailed drawing sheets, and comprehensive general requirements. The contractor must develop a Critical Path Method (CPM) schedule, maintain strict security protocols, and ensure minimal disruption to the Medical Center's 24/7 operations. Specific provisions cover site preparation, waste management, utility services coordination, and environmental controls. The project also mandates professional surveying, as-built drawings, and a robust warranty management plan with specified response times for repairs. Photographic documentation of construction progress and final elevations is required, along with immediate reporting of any archeological or historical discoveries. The contractor is responsible for all measurements, materials, and labor, ensuring compliance with all project schedules and safety requirements.
    S02. 757-24-204 - Parking Garage Tendon Repair - 100 Bid Documents-Stamped.pdf
    The document pertains to the construction documents for the Parking Garage Tendon Repair project at the Columbus VA Medical Center, detailing structural repair requirements, construction phasing, and safety protocols. It outlines the contractor's responsibilities, including obtaining permits, following applicable codes, and maintaining the worksite conditions. Additionally, it specifies the tasks related to beam and tendon repairs, the submission of work quantities, and adherence to environmental regulations during construction.
    S04. Sign In Sheet - Site Visit.pdf
    The document contains a series of contact tables listing individuals associated with various companies, primarily within the construction and healthcare sectors, along with their titles, phone numbers, and emails. Some entries include notable personnel from the U.S. Department of Veterans Affairs and their respective contact information. There are several formatting errors and incomplete entries throughout the tables.
    S06. 36C25026B0014 0001.pdf
    Amendment 0001 to solicitation 36C25026B0014, issued by the Department of Veterans Affairs, Regional Procurement Office Central, Network Contracting Office (NCO) 10, amends the original solicitation for project number 757-24-204. The amendment, effective December 1, 2025, serves to post the 100% Bid Document, Bid Master Specifications Document, and the Site Visit Sign-In Sheet. Crucially, the bid opening date and time for the Parking Garage Tendon Repair project remain December 22, 2025, at 1 PM EST. All other terms and conditions of the original solicitation remain unchanged. This modification ensures all potential offerors have access to comprehensive bidding information and site visit records prior to the submission deadline.
    Lifecycle
    Title
    Type
    Z1DA--Repair Parking Garage Tendon 757-24-204 - Construction - VAACC Columbus
    Currently viewing
    Solicitation
    Similar Opportunities
    Z1DA--Repair Parking Garage Tendon 757-24-204 - Construction - VAACC Columbus
    Buyer not available
    The Department of Veterans Affairs is soliciting bids for the repair of parking garage tendons at the Chalmer Wylie VA Ambulatory Care Center in Columbus, Ohio, under project number 757-24-204. The project involves correcting damaged tendons to restore the garage's structural integrity, with a total contract value estimated below $1,000,000. This work is critical for maintaining the safety and functionality of the facility, which serves veterans and requires minimal disruption during construction. Interested contractors must be verified as Service-Disabled Veteran-Owned Small Businesses (SDVOSB), registered in SAM, and submit their bids by December 22, 2025, with a site visit scheduled for December 1, 2025. For further inquiries, contact Contracting Officer Stanley Burdine at stanley.burdine@va.gov or 614-388-7827.
    539-25-505 Maintain Parking Garage Safety
    Buyer not available
    The Department of Veterans Affairs (VA) is soliciting offers for the "Maintain Parking Garage Safety" project at the Cincinnati Veterans Affairs Medical Center (VAMC). This project involves replacing waterproofing joint sealants, repairing concrete slabs damaged by water intrusion, and conducting a comprehensive structural survey of the garage, which will be performed by THP LTD. The work is critical for ensuring the safety and longevity of the parking structure, and it must be completed within 90 calendar days of receiving a Notice to Proceed, primarily during weekends to minimize disruption to VA operations. Interested contractors must submit their quotes by December 12, 2025, at 4:30 PM EST, via email to Samuel Galbreath at samuel.galbreath@va.gov, and are encouraged to attend a mandatory site visit on November 12, 2025, at 11 AM.
    Repair FTD Building Envelope 539-25-509
    Buyer not available
    The Department of Veterans Affairs is soliciting bids for the "Repair FTD Building Envelope" project at the Cincinnati VA Medical Center, specifically targeting infrastructure upgrades at the Fort Thomas Domiciliary. The project entails comprehensive renovations, including the repair of approximately 700 linear feet of parapet roof, waterproofing, structural reinforcement, installation of a lightning protection system, and restoration of the front patio accent wall, covering around 870 square feet. This construction effort is crucial for maintaining the safety and operational integrity of the facility, ensuring minimal disruption during the phased approach to the work. Interested contractors, certified as Service-Disabled Veteran-Owned Small Businesses (SDVOSB), must submit their quotes by January 7, 2026, at 1630 EST, and can direct inquiries to Samuel Galbreath at samuel.galbreath@va.gov. The contract is a Firm-Fixed-Price agreement under NAICS code 236220, with a performance period of 122 calendar days from the Notice to Proceed.
    Y1LZ--Expand B330 Staff Parking Lot 552-26-502
    Buyer not available
    The Department of Veterans Affairs (VA) is seeking qualified contractors for the expansion of the B330 Staff Parking Lot at the Dayton VA Medical Center, under project number 552-26-502. The project entails constructing an approximately 93,200 square foot gravel parking lot that will accommodate around 320 parking spaces, thereby enhancing the existing staff parking area. This procurement is a 100% set-aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSBs), with an estimated construction cost ranging from $250,000 to $500,000, and a projected period of performance of 90 calendar days. The solicitation is expected to be posted on SAM.gov around November 14, 2025, with proposals due approximately 30 days thereafter; interested parties should contact Contract Specialist Matthew Curtis at Matthew.Curtis1@va.gov for further inquiries.
    Z1DA--Relocate Infusion Clinic and Hemo Offices - 539-21-207
    Buyer not available
    The Department of Veterans Affairs is seeking a contractor for the relocation of the Infusion Clinic and Hemo Offices at the Cincinnati VA Medical Center. The project involves renovating approximately 2,056 gross square feet of space, including general construction, mechanical, electrical, plumbing, and technology trades, as well as asbestos and lead-based paint abatement. This construction effort is critical for enhancing healthcare services provided to veterans, with an estimated project value between $1,000,000 and $5,000,000. Interested service-disabled veteran-owned small businesses (SDVOSB) should contact Contracting Officer Patrice Scott at patrice.richardson-scott@va.gov or call 513-559-3718 for further details, with the Invitation for Bids expected to be posted around November 20, 2025.
    Z2DA--Repair and Replace Doors 539-22-202
    Buyer not available
    The Department of Veterans Affairs is soliciting bids for the "Repair and Replace Doors" project at the Cincinnati VA Medical Center and the Ft. Thomas Domiciliary in Kentucky. This procurement involves comprehensive demolition and installation of new doors, frames, and associated hardware across multiple buildings, with a focus on safety and compliance due to the presence of hazardous materials like asbestos and lead paint. The project is critical for maintaining operational integrity and security within the medical facilities, with an estimated value between $500,000 and $1,000,000 and a performance period of 730 calendar days. Bids are due by December 11, 2025, at 1:00 PM EST, and interested parties should contact Contract Specialist Ronald T. Heidemann at Ronald.Heidemann@va.gov for further information.
    Z2DA--Renovate MICU/SICU 539-20-104
    Buyer not available
    The Department of Veterans Affairs is soliciting bids for the renovation of the Medical Intensive Care Unit (MICU) and Surgical Intensive Care Unit (SICU) at the Cincinnati VA Medical Center, under project number 539-20-104. The project entails comprehensive renovations covering approximately 11,000 square feet, including demolition, new layouts, fixtures, finishes, and the installation of a HEPA pandemic filtration system, with an estimated construction value between $5,550,000 and $7,250,000. This procurement is particularly significant as it aims to modernize critical care facilities, ensuring compliance with safety and infection control standards while maintaining operational efficiency. Interested Service-Disabled Veteran-Owned Small Businesses (SDVOSB) must submit their bids by 1:00 PM EST on January 8, 2026, following a mandatory site visit scheduled for November 3, 2025. For further inquiries, contact Ronald T. Heidemann at Ronald.Heidemann@va.gov.
    Z1DA--Repair T5 Transformer 539-25-503
    Buyer not available
    The Department of Veterans Affairs, specifically the Network Contracting Office 10, is seeking proposals for the "Repair T5 Transformer Access Hatch" project at the Cincinnati Veterans Affairs Medical Center. The project involves the replacement of a three-phase pad mount 150 KVA T5 transformer, including the procurement of new equipment, installation, and proper disposal of the old transformer, with a performance period of 550 calendar days from the Notice to Proceed. This procurement is set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSBs) and has an estimated construction magnitude between $100,000 and $250,000. Interested contractors must submit their bids by December 18, 2025, at 1:30 PM EST, and are encouraged to attend a mandatory site visit on November 14, 2025. For further inquiries, contact Patrice Scott at patrice.richardson-scott@va.gov or call 513-559-3718.
    Z1DA--Renovate B26 for Mental Health - 538-23-102 Chillicothe VAMC
    Buyer not available
    The Department of Veterans Affairs (VA) is seeking qualified contractors for the renovation of Building 26 for Mental Health at the Chillicothe VA Medical Center, under Project 538-23-102. This project, exclusively set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB), involves a partial renovation of approximately 19,000 square feet of the existing Sustained Behavioral Treatment Unit (SBTU), including necessary architectural, mechanical, electrical, and plumbing upgrades, as well as the construction of a new basement floor for an Air Handling Unit (AHU). The estimated project duration is 320 calendar days, with a funding range between $2,000,000 and $5,000,000, and a solicitation is anticipated to be issued around November 12, 2025. Interested parties should contact Contract Specialist Jeremy Nee at jeremy.nee@va.gov for further information and ensure they are registered on the appropriate government websites to participate in the procurement process.
    Z2DA--Resurface Parking Garage C
    Buyer not available
    The Department of Veterans Affairs (VA) is soliciting proposals for design-build services to resurface Parking Garage C at the VA Caribbean Healthcare System (VACHS) in San Juan, Puerto Rico. The project aims to restore the structural integrity and surface condition of the garage, addressing issues such as deterioration, drainage improvements, and safety system upgrades. This opportunity is particularly significant as it is set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB), emphasizing the VA's commitment to supporting veteran entrepreneurs. Interested contractors must submit their technical and price proposals in a two-phase process, with the contract period spanning 730 days, contingent on fund availability. For further inquiries, potential bidders can contact Contracting Officer Ana G. Alvarado at ana.alvarado@va.gov.