Z1DA--Repair Parking Garage Tendon 757-24-204 - Construction - VAACC Columbus
ID: 36C25026B0014Amend0001Type: Solicitation
Overview

Buyer

DEPARTMENT OF VETERANS AFFAIRSVETERANS AFFAIRS, DEPARTMENT OF250-NETWORK CONTRACT OFFICE 10 (36C250)DAYTON, OH, 45428, USA

NAICS

Commercial and Institutional Building Construction (236220)

PSC

MAINTENANCE OF HOSPITALS AND INFIRMARIES (Z1DA)

Set Aside

Service-Disabled Veteran-Owned Small Business Set Aside (SDVOSBC)
Timeline
    Description

    The Department of Veterans Affairs is soliciting bids for the repair of the parking garage tendon at the Columbus VA Medical Center under project number 757-24-204. This construction project involves the repair and restressing of damaged beam tendons, requiring adherence to VA Master Specifications, detailed drawings, and a comprehensive project management plan that includes a Critical Path Method (CPM) schedule and strict security protocols to minimize disruption to the Medical Center's operations. The bid opening is scheduled for December 22, 2025, at 1 PM EST, and interested contractors can obtain further details by contacting Contracting Officer Stanley Burdine at stanley.burdine@va.gov or by phone at 614-388-7827.

    Point(s) of Contact
    Stanley BurdineContracting Officer
    (614) 388-7827
    stanley.burdine@va.gov
    Files
    Title
    Posted
    The Columbus VAMC VA Project 757-24-204 outlines the specifications for the Parking Garage Tendon Repair Design, due by July 18, 2025. This project involves the repair and restressing of damaged beam tendons. Key requirements include adherence to VA Master Specifications, detailed drawing sheets, and comprehensive general requirements. The contractor must develop a Critical Path Method (CPM) schedule, maintain strict security protocols, and ensure minimal disruption to the Medical Center's 24/7 operations. Specific provisions cover site preparation, waste management, utility services coordination, and environmental controls. The project also mandates professional surveying, as-built drawings, and a robust warranty management plan with specified response times for repairs. Photographic documentation of construction progress and final elevations is required, along with immediate reporting of any archeological or historical discoveries. The contractor is responsible for all measurements, materials, and labor, ensuring compliance with all project schedules and safety requirements.
    The document pertains to the construction documents for the Parking Garage Tendon Repair project at the Columbus VA Medical Center, detailing structural repair requirements, construction phasing, and safety protocols. It outlines the contractor's responsibilities, including obtaining permits, following applicable codes, and maintaining the worksite conditions. Additionally, it specifies the tasks related to beam and tendon repairs, the submission of work quantities, and adherence to environmental regulations during construction.
    The document contains a series of contact tables listing individuals associated with various companies, primarily within the construction and healthcare sectors, along with their titles, phone numbers, and emails. Some entries include notable personnel from the U.S. Department of Veterans Affairs and their respective contact information. There are several formatting errors and incomplete entries throughout the tables.
    Amendment 0001 to solicitation 36C25026B0014, issued by the Department of Veterans Affairs, Regional Procurement Office Central, Network Contracting Office (NCO) 10, amends the original solicitation for project number 757-24-204. The amendment, effective December 1, 2025, serves to post the 100% Bid Document, Bid Master Specifications Document, and the Site Visit Sign-In Sheet. Crucially, the bid opening date and time for the Parking Garage Tendon Repair project remain December 22, 2025, at 1 PM EST. All other terms and conditions of the original solicitation remain unchanged. This modification ensures all potential offerors have access to comprehensive bidding information and site visit records prior to the submission deadline.
    Lifecycle
    Similar Opportunities
    Loading similar opportunities...