TINKER AFB MAC BOA WWYK240149 RENOVATE NE AREA OF SOUTH PROJECT, B3
ID: FA813725R0016Type: Solicitation
Overview

Buyer

DEPT OF DEFENSEDEPT OF THE AIR FORCEFA8137 AFSC PZIOCTINKER AFB, OK, 73145-9125, USA

NAICS

Commercial and Institutional Building Construction (236220)

PSC

REPAIR OR ALTERATION OF OFFICE BUILDINGS (Z2AA)

Set Aside

Total Small Business Set-Aside (FAR 19.5) (SBA)
Timeline
  1. 1
    Posted Mar 31, 2025, 12:00 AM UTC
  2. 2
    Updated Apr 10, 2025, 12:00 AM UTC
  3. 3
    Due May 12, 2025, 8:00 PM UTC
Description

The Department of Defense, through the Air Force, is soliciting proposals from qualified contractors for the renovation of the northeast area of Building 3 at Tinker Air Force Base in Oklahoma, designated as project WWYK240149. The project entails extensive upgrades, including the repair and replacement of HVAC systems, reconfiguration of lighting and electrical feeds, installation of fire alarm devices, and enhancements to flooring and wall structures to accommodate new systems furniture layouts. This renovation is crucial for modernizing the facilities to meet current operational standards and safety regulations, ensuring compliance with federal guidelines throughout the construction process. Interested contractors, particularly those holding a MAC BOA, must submit their proposals by April 21, 2025, and are encouraged to contact Eric Owens at eric.owens.8@us.af.mil or Stephen Palmer at stephen.palmer@us.af.mil for further details regarding the solicitation and project requirements.

Files
Title
Posted
Apr 10, 2025, 8:06 PM UTC
The Tinker Air Force Base (TAFB) General Requirements document outlines the essential construction guidelines for contractors operating on the base. It references various industry standards, safety codes, and operational procedures, such as the National Fire Protection Association (NFPA) standards related to construction safety and fire prevention. Key points include security protocols for contractors, work scheduling in line with base operations, utility management, and processes for submitting requests related to outages and site closures. Contractors must follow strict procedures, including obtaining identification badges, providing advance notices for work commencement, and adhering to specified work hours, including federal holidays. Additionally, contractors are responsible for maintaining site cleanliness, managing As-built drawings, and ensuring compliance with utility protections during excavation. The document emphasizes that procedures must focus on safety and coordination to prevent disruption to base operations and aims to ensure a high standard of work quality and safety throughout the construction process. These requirements are vital for compliance with federal regulations and for successful project outcomes on Tinker AFB.
Apr 10, 2025, 8:06 PM UTC
The Tinker Air Force Base (TAFB) document outlines the General Safety Requirements for construction activities at the base. It references various key publications, including safety regulations from the U.S. Air Force, Army Corps of Engineers, and Occupational Safety and Health Administration (OSHA). The document mandates that contractors submit a comprehensive Health and Safety Plan, ensuring that construction activities do not expose workers or military personnel to health hazards. Critical aspects include emergency evacuation procedures, mishap reporting protocols, confined space entry regulations, and FOD (Foreign Object Debris) prevention training. Contractors must adhere to specific airfield safety protocols, securing necessary waivers before commencing work, and ensuring vehicle and equipment compliance with operational safety standards. The document highlights a push towards achieving OSHA Voluntary Protection Program (VPP) certification, emphasizing a commitment to workplace safety. Overall, this file serves as a critical guideline for contractors, reinforcing responsibility for safety, compliance with federal regulations, and cooperation with base authorities in all construction-related activities at TAFB.
Apr 10, 2025, 8:06 PM UTC
The Tinker Air Force Base's Environmental Requirements for Construction outlines essential environmental protections to be observed during any construction activity at the Base. This document emphasizes compliance with relevant federal, state, and local environmental regulations to prevent pollution impacting land, water, and air resources. Key sections address the protection of land resources, including tree preservation and erosion control, alongside water resources which focus on storm water quality management and waste disposal. The guidelines prohibit the discharge of hazardous materials into waterways and mandate a Storm Water Pollution Prevention Plan for larger projects. The document incorporates requirements for hazardous material reporting, the management of refrigerants and asbestos, and protocols for addressing any potential archaeological finds during construction. The responsibilities of the contractor include ensuring training on environmental policies and taking measures for pollution control in air quality and waste management. Additionally, it highlights the necessity for green procurement practices and the use of environmentally preferable products. Overall, the aim is to minimize environmental impact and ensure compliance with health and safety standards throughout construction activities at Tinker AFB.
Apr 10, 2025, 8:06 PM UTC
This document outlines special provisions for contractors working at Tinker Air Force Base (TAFB). It establishes essential guidelines, including necessary references and requirements regarding dewatering excavated areas to prevent damage from rainwater, utilization of designated haul routes, and coordination with the Contracting Officer for all airfield operations. Key regulations dictate that all construction activities must not impede runway, taxiway, or apron access unless authorized. Contractors must ensure the safety of vehicle operations in high-traffic areas, maintaining effective communication with Tinker Ground Control. Furthermore, adequate traffic control measures must be in place, following U.S. Department of Transportation standards, while waste materials removed are the contractor's responsibility for disposal. A provision allows for a winter recess from December 1 to March 1, with a no-cost modification to the contract. Overall, these provisions aim to ensure safety, minimize disruption during construction, and comply with military operational standards at Tinker AFB.
Apr 10, 2025, 8:06 PM UTC
The document outlines special provisions for contractors working on or near the active airfield at Tinker AFB. It emphasizes the necessity for meticulous planning and coordination for runway and taxiway closures, requiring written requests 45 days in advance, detailing the nature and duration of the work. It mandates proper safety measures, including the provision of hearing protection for personnel and strict maintenance of a clean worksite to prevent Foreign Object Damage (FOD) to aircraft. Access restrictions are defined, necessitating clearance from the control tower for contractor vehicles, which must display specific safety lights. Temporary structures or equipment exceeding designated heights require prior approval. The contractor is responsible for ensuring a designated evacuation area and must act promptly in emergencies. Regular inspections and cleaning of the airfield areas are enforced to safeguard operational safety. This document serves as a critical guideline for ensuring safety, compliance, and operational integrity during construction activities at Tinker AFB, reflecting the stringent protocols applicable in military and government settings.
Apr 10, 2025, 8:06 PM UTC
The document outlines the general requirements and regulations for construction activities at Tinker Air Force Base (AFB), effective January 2022. It is organized into several sections, starting with procurement and contracting requirements, which include safety and environmental considerations specific to Tinker AFB. Additionally, special provisions detail protocols for work on or near the airfield, emphasizing adherence to safety and operational standards critical to military installations. Key sections include guidelines for small project schedules, submittal procedures, quality control, contractor facilities, and closeout submittals, all designed to ensure compliance and effectiveness during construction efforts. This thorough framework aims to safeguard both personnel and infrastructure by establishing clear expectations for contractors engaging in federally funded projects at the base. Overall, this document serves as a vital resource for contractors and stakeholders involved with RFPs and grants at Tinker AFB, promoting safety, environmental stewardship, and operational efficiency throughout construction projects. Understanding these requirements is essential for successful project execution while aligning with federal and local regulations.
Apr 10, 2025, 8:06 PM UTC
The document appears to list various elements pertaining to federal and state/local Requests for Proposals (RFPs) and grants. It features a coded format with alphanumeric sequences that likely categorize different RFPs or grant programs, though specific topics and details are not explicitly stated. This format may correlate to various projects or funding opportunities within the federal and state government frameworks. The existence of numerals, letters, and slashes suggests a systematic organization, possibly for internal tracking or cataloging purposes, indicating a complex structure that conveys information in a concise manner. However, without further context or elaboration, the primary subjects or areas of focus remain unclear. This file likely serves as a resource for stakeholders looking to identify and engage with various government-funded projects.
Apr 10, 2025, 8:06 PM UTC
The document outlines the requirements for small project construction progress schedules at Tinker Air Force Base. It details the submission process for baseline construction and design schedules, specifying that these must be approved by the government before any demolition or construction begins. The Contractor is responsible for maintaining a Network Analysis Schedule (NAS) or Bar Chart Schedule using Microsoft Project and adhering to critical path method (CPM) principles. The schedule must include various project activities, ensure no open-ended tasks, and identify critical milestones such as "Contract Award" and "Contract Completion." Additional requirements include monthly updates of the schedule, tracking narrative reports, and preparation of a 3-week look-ahead schedule to detail upcoming work. The document also explains how to handle delays and necessary time impact analyses (TIAs) for contract modifications, emphasizing the classification of delays (force majeure, contractor delays, government delays), and their implications on contract time. Overall, this document serves to ensure that construction activities at Tinker AFB are planned, monitored, and executed effectively, while complying with federal contracting regulations.
Apr 10, 2025, 8:06 PM UTC
The document outlines the submittal procedures for contractors engaged in projects at Tinker Air Force Base. It details the requirements for submitting various types of materials and documentation, ensuring compliance with contract specifications. Each submittal must include thorough descriptions and supporting materials, such as drawings, product data, and test reports, which must be reviewed and approved by designated authorities, including the Contracting Officer and the Designer of Record. Different categories of submittals are defined (e.g., preconstruction, shop drawings, product data), each with specific formatting and submission guidelines. The document emphasizes the importance of timely submissions to avoid delays in the project schedule and mandates maintaining a submittal register to manage and track all entries. Additionally, it discusses how variations from contract requirements must be documented and approved. Overall, this procedure ensures that contractors adhere strictly to project requirements, facilitating efficient project management and compliance with government standards.
Apr 10, 2025, 8:06 PM UTC
The Tinker AFB General Requirements document outlines comprehensive design process guidelines post-award for construction projects. It emphasizes a collaborative, integrated approach focused on sustainability through energy and material efficiency, along with waste management. The document sets forth standards referencing multiple organizations, including ISO, NFPA, and DOD, ensuring compliance and quality throughout project phases. Key roles like the Designer of Record are defined, alongside expectations for government interactions, including meetings and submittal protocols. The design submission is structured in phases, requiring documentation at various intervals—interim, final, and complete designs—each necessitating quality control checks and adherence to specific formats and standards. Advanced Modeling techniques are highlighted, stressing the necessity for electronic submissions to be virus-free and compliant with established CAD and GIS standards. Overall, the document serves to ensure that projects executed meet stringent federal requirements while fostering high-quality design and construction practices.
Apr 10, 2025, 8:06 PM UTC
The document pertains to Tinker Air Force Base's general requirements regarding references for construction-related works. It outlines the necessary references to various standards and publications required for the project, detailing the standards organizations and how to obtain their documents. Key organizations listed include the International Organization for Standardization (ISO), National Fire Protection Association (NFPA), and U.S. Army Corps of Engineers (USACE), among others. Contact information, including addresses, phone numbers, emails, and websites, are provided for each organization to facilitate access to their respective publications. The document emphasizes adherence to established standards for ensuring quality and safety in construction endeavors, aligning with regulatory frameworks applicable to federal government RFPs and grants. This structured approach aids in maintaining compliance and thorough documentation throughout the project lifecycle.
Apr 10, 2025, 8:06 PM UTC
The document outlines the Quality Control (QC) requirements for construction projects at Tinker Air Force Base. It specifies the establishment and maintenance of a comprehensive QC system that aligns with federal standards, particularly FAR 52.246-12 on construction inspection. The key components include submitting a QC Plan for government approval, defining roles and responsibilities within the QC organization, and documenting various phases of quality control, including Preparatory, Initial, and Follow-up phases. The QC Manager plays a pivotal role, managing all QC activities and ensuring compliance with contract specifications. Additional focus is given to the Design Quality Control Plan that mandates an independent review of design documents to uphold engineering standards. Coordination meetings with the contracting officer are essential for clarifying QC processes and addressing concerns. The document emphasizes rigorous documentation, including daily reports, testing logs, and punch lists, essential for effective oversight and compliance. Moreover, it stipulates that all personnel involved in QC must have relevant experience, with more stringent requirements for specialized roles. This comprehensive approach ensures the integrity and quality of construction at the site, reflecting government expectations for compliance and safety protocols.
Apr 10, 2025, 8:06 PM UTC
The document outlines the general requirements for contractor facilities at Tinker Air Force Base (TAFB), specifically focusing on the management of staging areas for materials and equipment during construction. Contractors are required to limit storage to designated areas, maintain cleanliness, provide necessary utilities at their own expense, and ensure site security. A process for requesting additional staging areas is established, necessitating a written application to the Contracting Officer 21 days prior to mobilization. Safety protocols demand compliance with various regulations, including providing first aid kits and fire extinguishers. The contractor is responsible for restoring the staging area post-contract to its original condition. The document serves to ensure organized, safe, and compliant construction operations in federal projects, highlighting responsibilities and operational standards vital for contractors engaging with the government. Overall, it emphasizes the importance of safety, security, and proper site management in military construction environments.
Apr 10, 2025, 8:06 PM UTC
The document outlines the closeout submittal requirements for contracts at Tinker Air Force Base, focusing on the preparation and submission of working as-built drawings, record drawings, and necessary documentation. It includes references to U.S. Army Corps of Engineers standards and the Department of Defense's criteria for property transfer. Key components comprise the maintenance of accurate as-built documentation throughout construction, the submission of electronic CAD files compliant with specific standards, and warranties covering various construction aspects. The process necessitates government approval for specific submittals related to operation and maintenance manuals, warranty letters, and compliance certifications with EPA and USDA designations. The contractor is responsible for adjusting documentation based on actual site conditions, reporting changes clearly in a designated format, and ensuring all submittals comply with quality control measures. Additionally, the document outlines procedures for final inspections, cleanup requirements, and property accounting using a specified DD Form 1354. This systematic approach aims to ensure effective project closeout and compliance with federal regulations while facilitating future maintenance efforts.
Apr 10, 2025, 8:06 PM UTC
The document outlines the operational and maintenance requirements for systems at Tinker Air Force Base, focusing on the submission and organization of Operation and Maintenance (O&M) data packages. It specifies that certain submissions must receive government approval, detailing various types of data required, such as training plans, operational instructions, preventive maintenance schedules, and troubleshooting guides. Each O&M data package is categorized to facilitate compliance, with specific instructions for content organization, including legible presentation and adherence to manufacturer standards. The sections emphasize the importance of clear operating instructions, maintenance protocols, and comprehensive training for maintenance personnel, including validation of training completion. The structured requirements ensure system reliability, enhance safety, and guarantee long-term operational effectiveness in line with federal regulations. Overall, the document serves to standardize maintenance practices and training at the facility, supporting consistent operation across multiple systems and equipment.
Apr 10, 2025, 8:06 PM UTC
Apr 10, 2025, 8:06 PM UTC
The Tinker Air Force Base Facility Standard outlines the minimum requirements for construction quality, life safety features, and infrastructure projects at TAFB. Issued in August 2020, the document is maintained by the 72nd Air Base Wing's Base Civil Engineer (BCE) office and applies to various project types including Military Construction Projects (MCP), service contracts, and self-help projects. Key sections include project procedures, civil engineering records, design criteria, cost estimating, and construction documentation formats. The standard emphasizes compliance with federal regulations and codes, which encompass safety, accessibility, and environmental considerations. Facility projects must incorporate various design standards, including the National Fire Protection Association (NFPA) codes and the Occupational Safety and Health Administration (OSHA) regulations. The document also addresses utility systems, environmental compliance, and preservation of historical resources. Overall, the Facility Standard serves as a comprehensive guide for contractors and designers to ensure safety, functionality, and environmental protection during the design and construction processes at Tinker AFB, reinforcing the base’s commitment to quality and adherence to government regulations.
Apr 10, 2025, 8:06 PM UTC
The "Base Mechanical Standard" document issued for Tinker Air Force Base (TAFB) outlines stringent requirements and standards for energy conservation, fire protection, plumbing systems, and HVAC/R systems as part of facility upgrades and renovation projects. The primary focus is on ensuring compliance with applicable United Facilities Criteria (UFC), Air Force Instructions (AFI), and energy efficiency standards to minimize fossil fuel usage. Key areas covered include: 1. **Energy Conservation:** Mandates for energy-efficient designs in mechanical systems, energy usage metering, and lifecycle cost analyses to promote sustainability. 2. **Fire Protection Engineering:** Requirements for professional design by qualified engineers, compliance with fire safety standards, and addressing any existing safety deficiencies. 3. **Plumbing Systems:** Protocols for designing plumbing infrastructure meeting various codes and ensuring accessibility, safety, and maintenance ease. 4. **HVAC/R Systems:** Directives for system design ensuring occupant safety, mechanical system operation, performance testing, and efficient operation. The document serves to standardize facility practices at TAFB, ensuring safety, compliance with regulations, and integration of modern technologies in facility management while promoting energy and operational efficiencies.
Apr 10, 2025, 8:06 PM UTC
The document outlines a construction project at Tinker Air Force Base, focusing on repairs to the roof of a facility as managed by the Air Force Materiel Command. The project entails removing existing roofing materials, including built-up roofing (BUR) systems, and replacing them with a new EPDM roofing system, gutters, and metal wall panels. It emphasizes the contractor’s responsibility to ensure safety during construction and the need to coordinate renovations with existing conditions, including addressing potential wood rot. Detailed structural specifications are provided, including load calculations for roofing and material grades. The contractor is instructed to verify all dimensions and existing conditions and correctly handle any hazardous materials if encountered. The project spans various stages of demolition and replacement, centered on improving the building’s structural integrity and compliance with applicable building codes. This document serves to guide contractors through the RFP process by detailing expectations for the repairs while ensuring safety, compliance, and quality in construction practices. Overall, it reflects the government's commitment to maintaining military readiness through facility upgrades.
Apr 10, 2025, 8:06 PM UTC
The Tinker Air Force Base (AFB) Fire Protection Standard, issued in March 2023, outlines the fire protection and life safety requirements for facility planning, design, construction, and commissioning specific to Tinker AFB, Oklahoma. This document establishes minimum standards adhering to the Unified Facilities Criteria (UFC) and includes details on fire-rated walls, firestopping qualifications, inspection protocols, and approved materials. It mandates pre-contractual meetings involving project stakeholders to ensure fire safety integration. Key features include contractor qualifications for firestopping, sprinkler, fire alarm, and special hazards systems, specifying NICET certifications and documentation for compliance. It also sets standards for fire hydrants, fire lanes, automated sprinkler systems, alarm notifications, and emergency messaging protocols geared toward various scenarios including fire emergencies and carbon monoxide detection. The intent of this standard is to ensure all fire protection measures conform to safety regulations while facilitating efficient emergency response capabilities. It serves as a guideline for contractors and engineers involved in projects at Tinker AFB, aligning operational efficiency and safety through detailed documentation and rigorous compliance checks.
Apr 10, 2025, 8:06 PM UTC
The TAFB Electrical Standards document outlines the requirements for all electrical work performed at Tinker Air Force Base, Oklahoma, as of 2024. It mandates adherence to the latest editions of various electrical codes, standards, and Unified Facility Criteria (UFC). The document emphasizes design adherence to specifications, including the use of existing as-built drawings for reference and verification of conditions on-site. Key considerations in electrical design include load capacity, energy analysis, and future load growth. Installation standards call for certified professionals to ensure reliability and quality standards. The document also specifies detailed requirements for circuit identification, color coding, and installation methods for electrical equipment, highlighting safety measures such as arc flash analysis and proper labeling of equipment. Additionally, provisions for exterior and interior electrical systems are defined, including underground distribution methods, metering standards, and environmental considerations for emergency generators. This comprehensive framework aims to enhance operational efficiency and safety at Tinker AFB while ensuring compliance with federal and military regulations, thus guiding contractors and engineers in managing electrical projects on the base.
Apr 10, 2025, 8:06 PM UTC
The document outlines a construction project at Tinker Air Force Base, focusing on the renovation of the northeast area of the South Project (WWYK240149). The primary objective is to renovate existing structures while adhering to safety and quality standards, including managing asbestos and ensuring compliance with fire safety measures. Contractors are required to follow a comprehensive set of specifications, including responsibilities for site protection, repair of any damages caused during construction, and ensuring all labor and materials meet specified standards. The document includes a project drawing index, general notes on architectural demolition, and renovation plans, emphasizing verified field conditions. Fire protection and life safety concerns are central, dictating alterations to existing safety systems. Overall, this comprehensive renovation project enhances the functionality and safety of facilities at Tinker AFB while aligning with government contractual and regulatory requirements.
Apr 10, 2025, 8:06 PM UTC
The Statement of Work (SOW) outlines the renovation project for the NE area of Building 3 at Tinker Air Force Base, focusing on the replacement of HVAC systems, lighting fixtures, and other infrastructural elements. The contractor is responsible for all design, materials, labor, and quality control associated with the project. Key personnel requirements include a Project Manager with extensive experience, a qualified Design Project Manager, and a Quality Control Manager. The contractor must ensure all employees possess valid certifications and adhere to safety protocols as mandated by federal regulations. The project entails substantial architectural demolition and construction, especially in conference rooms and workspaces, to integrate new systems furniture and comply with safety standards. Quality assurance processes, including regular inspections and reporting, are critical to ensuring adherence to project specifications. The document emphasizes a collaborative approach with timely communication between contractors and government representatives. Furthermore, environmental management must address potential hazardous materials, necessitating thorough assessments before construction begins. This SOW demonstrates the government's effort to maintain efficient operational standards while modernizing facilities in line with contemporary requirements.
Apr 10, 2025, 8:06 PM UTC
The document is a Submittal Register for a construction project titled "Renovate NE Area of South Project". It outlines required preconstruction and closeout submissions to ensure compliance with federal and state regulations. Each entry includes specifications such as submittal descriptions, classification (GOVT or A/E), submission deadlines, and documentation requirements. Key aspects covered include health and safety plans, environmental management procedures, quality control measures, and detailed schedules for various stages of the construction process. Specific emphasis is placed on meeting regulatory criteria, such as permits for hazardous materials, safety documents, and post-construction evaluations including as-built drawings. The register facilitates organization and timely submission of essential documents to project authorities, reinforcing accountability and compliance throughout the construction lifecycle. This systematic approach is vital for safeguarding public health and safety while ensuring adherence to government standards in federal grants and RFPs.
Apr 10, 2025, 8:06 PM UTC
The document is a Submittal Register for a construction project titled "Renovate NE Area of South Project". It outlines required preconstruction and closeout submissions to ensure compliance with federal and state regulations. Each entry includes specifications such as submittal descriptions, classification (GOVT or A/E), submission deadlines, and documentation requirements. Key aspects covered include health and safety plans, environmental management procedures, quality control measures, and detailed schedules for various stages of the construction process. Specific emphasis is placed on meeting regulatory criteria, such as permits for hazardous materials, safety documents, and post-construction evaluations including as-built drawings. The register facilitates organization and timely submission of essential documents to project authorities, reinforcing accountability and compliance throughout the construction lifecycle. This systematic approach is vital for safeguarding public health and safety while ensuring adherence to government standards in federal grants and RFPs.
Apr 10, 2025, 8:06 PM UTC
The Recovered Materials Determination Form (RMDF) is a crucial document used by federal entities to ensure compliance with environmental standards during procurement actions. Its primary purpose is to identify products classified under the Comprehensive Procurement Guidelines (CPG), assess energy efficiency, and document any exemptions related to these products. The RMDF is applicable to all procurement actions excluding GPC purchases and must be filled out for any items that fall under CPG, biobased, Energy Star®, or FEMP Low Standby Power categories. Contractors and personnel must complete the RMDF when procuring mandatory environmentally preferable purchasing items. If not applicable, a Green Procurement Statement must be submitted instead. The completed RMDF, along with any amendments, should be kept in the purchasing or contracting file for compliance checks. Additionally, the form requires a signer knowledgeable about the products being purchased. The document outlines specific categories of recovered materials and biobased items being procured, ranging from construction materials to office products, emphasizing the importance of sustainability in government procurement processes. Ultimately, this form serves to facilitate environmentally responsible purchasing by documenting the consideration of recovered materials in federal contracts, ensuring adherence to government regulations and promoting green procurement practices.
Apr 10, 2025, 8:06 PM UTC
The document outlines a comprehensive design narrative for the renovation of the northeast area of Building B3 at Tinker Air Force Base in Oklahoma, designated as project number WWYK240149. The plan involves extensive architectural, mechanical, electrical, and fire protection upgrades to adapt the existing office environment for a new furniture layout. Key aspects include adherence to applicable codes and standards, such as the International Building Code and National Fire Protection Association regulations, ensuring life safety and compliance during construction. The renovation will modify existing HVAC systems, reconfigure office layouts with new construction and finishes, and enhance fire protection features, including sprinkler and alarm systems. The document details specific areas requiring work, addresses mechanical load calculations, and emphasizes air quality maintenance in line with established guidelines. The project proposal reflects the government's commitment to modernization, enhanced functionality, and safety within military facilities, aligning with federal compliance for construction projects.
Apr 10, 2025, 8:06 PM UTC
Apr 10, 2025, 8:06 PM UTC
Apr 10, 2025, 8:06 PM UTC
Apr 10, 2025, 8:06 PM UTC
Apr 10, 2025, 8:06 PM UTC
Apr 10, 2025, 8:06 PM UTC
This government solicitation outlines a request for proposals for the renovation of the northeast area of Building 3 at Tinker Air Force Base, Oklahoma. The project involves extensive work, including HVAC repairs, lighting and electrical reconfigurations, installation of fire alarm systems, flooring updates, and construction of walls and doors tailored to accommodate new systems furniture. The estimated budget for this endeavor ranges between $250,000 and $500,000, though funding is currently unavailable, which means that awards will be contingent upon future financial allocations. Bids are to be submitted by April 21, 2025, with specific instructions regarding performance and payment bonds, documentation requirements, and an emphasis on compliance with federal regulations, including the Buy American Act. This project requires adherence to extensive safety and inspection standards, ensuring quality control throughout the renovation process. The overall goal is to modernize the facilities while aligning with the federal contracting guidelines for construction and maintaining the commitment to using domestic materials wherever applicable.
Apr 10, 2025, 8:06 PM UTC
The Unified Master Reference List (UMRL) serves as a comprehensive compilation of publications referenced in the Unified Facilities Guide Specifications (UFGS) utilized by the U.S. Army Corps of Engineers, U.S. Navy Naval Facilities Engineering Systems Command, and U.S. Air Force Civil Engineer Center. It categorizes documents by organization name to avoid confusion caused by acronyms. Each organization with joint publications is listed under its respective proponent organization, which simplifies document referencing and ordering. The UMRL includes essential specifications related to various industries, such as acoustics, construction, HVAC, and structural engineering, among others. A significant feature is the automatic editing capability of the guide specification section UFGS-01 42 00, which integrates the listed references based on the project specifications through the SpecsIntact system. Updated periodically, the UMRL is accessible in an electronic format, supporting federal RFPs, grants, and local RFPs by providing a standardized resource for contractors and engineers engaged in projects requiring adherence to specified guidelines and standards. This document emphasizes uniformity and adherence to established practices, essential for efficient collaboration in government-funded projects.
Lifecycle
Title
Type
Solicitation
Similar Opportunities
TINKER AFB MAC BOA WWYK200132, Renovate Restrooms - B2121, Posts C7, 2C7, B19, and 2B19
Buyer not available
The Department of Defense, through the Department of the Air Force, is soliciting proposals from qualified contractors for the renovation of restroom facilities at Tinker Air Force Base, specifically under project WWYK200132. The project aims to modernize and upgrade men's and women's restrooms, showers, and janitor closets within Building 2121 and associated posts, ensuring compliance with current safety and accessibility standards. This renovation is crucial for enhancing the working conditions for military personnel and maintaining operational efficiency at the base. Interested contractors, who must be holders of the MAC BOA, are required to submit their proposals by April 21, 2025, and must attend an initial site visit to be eligible for consideration. For further inquiries, contractors can contact TSgt Tayla Begnaud at tayla.begnaud@us.af.mil or Brent Rockow at brent.rockow.1@us.af.mil.
TINKER AFB MAC BOA WWYK140020, REPLACE UNIT SUBSTATION AND SWITCHGEAR, COL V51,B3001
Buyer not available
The Department of Defense, through the Department of the Air Force, is soliciting proposals from qualified contractors for the replacement of the unit substation and switchgear at Tinker Air Force Base, Oklahoma, specifically at Post V51 in Building 3001. The project involves the demolition of outdated electrical equipment and the installation of new switchgear and transformers, ensuring compliance with applicable National Electrical Code (NEC) and National Fire Protection Association (NFPA) standards. This initiative is crucial for maintaining and upgrading military infrastructure to meet contemporary operational standards, thereby enhancing the facility's electrical capacity and safety. Interested contractors who are holders of the Tinker AFB MAC BOA must RSVP for an initial site visit by April 14, 2025, with the visit scheduled for April 15, 2025, at 10:30 AM CT. For further inquiries, contractors can contact Sara Hinds at sara.hinds.2@us.af.mil or Megan Hardeman at megan.hardeman@us.af.mil.
Bldg 300, Bay E Renovation Effort for Rooms 417 and 420
Buyer not available
The Department of Defense, specifically the Department of the Air Force, is seeking contractors for the renovation of Rooms E417 and E420 in Building 300 at Robins Air Force Base, Georgia. The project aims to design, construct, and install cubicles and modular walls while ensuring compliance with Base Facility Standards, ergonomic guidelines, and safety regulations to maximize occupancy and functionality in the workspace. This renovation is crucial for enhancing operational effectiveness and team cohesion by providing comfortable and designated work areas for employees, addressing current limitations in office space. Interested parties should coordinate a site visit scheduled for April 8, 2025, at 1400, with Matthew Loomis, and submit their Statements of Work to Michele Watts or Patrick Madan via email.
FA462025R0002 - Renovate (RM) Building 2245/2248/2249
Buyer not available
The Department of Defense, specifically the Department of the Air Force, is seeking contractors for the renovation of buildings 2245, 2248, and 2249 at Fairchild Air Force Base in Washington. The project aims to consolidate various user groups into a single facility, requiring comprehensive construction efforts including design-build, demolition, hazardous material abatement, and various utility and landscaping works. This opportunity is set aside for small businesses, with an estimated contract value between $25 million and $100 million, and a performance period of 910 calendar days divided into three phases. Interested contractors should prepare for a pre-proposal conference and ensure they are registered in the System for Award Management (SAM) before the anticipated RFP release on May 1, 2025, with proposals due by June 3, 2025. For further inquiries, contact Samantha Gorman at samantha.gorman@us.af.mil or Richard Hedrick at richard.hedrick.2@us.af.mil.
Offutt AFB Multiple Award Construction Contract (MACC)
Buyer not available
The Department of Defense, through the Department of the Air Force, is soliciting proposals for a Multiple Award Construction Contract (MACC) at Offutt Air Force Base in Nebraska. This contract aims to fulfill a variety of construction and design-build projects, with a focus on small businesses and other socio-economic set-asides, intending to award contracts to at least eight qualified offerors. The projects will include significant tasks such as the repair of a water main and HVAC systems, with estimated costs ranging from $250,000 to $1 million. Interested contractors must submit their proposals by April 28, 2025, and can direct inquiries to Michael Madison or Cassandra Janousek via email for further clarification.
B282 Security System Upgrade
Buyer not available
The Department of Defense, specifically the Department of the Air Force, is seeking contractors for the B282 Security System Upgrade at Tinker Air Force Base in Oklahoma. The project involves assessing and upgrading the current intrusion detection system (IDS) and access control system (ACS), as well as the removal and installation of related equipment, all in compliance with the latest Technical Specifications for Sensitive Compartmented Information Facilities. This upgrade is critical for maintaining the security and operational integrity of classified facilities, ensuring adherence to safety and environmental regulations throughout the process. Interested contractors should contact Robert Baker at robert.baker.60@us.af.mil or call 713-969-8916 for further details.
W912HN25BA007 (W912HN25B4002) Renovate Bldg. 59D Robins AFB, GA
Buyer not available
The Department of Defense, through the U.S. Army Corps of Engineers Savannah District, is soliciting bids for the renovation of Building 59D at Robins Air Force Base, Georgia, under solicitation number W912HN25BA007. The project involves extensive repairs and upgrades to approximately 142,202 square feet of facility space, including the replacement of critical systems such as the fire control system, HVAC controls, and structural elements like the concrete dock floor and trench drain system. This renovation is vital for maintaining operational capabilities and ensuring safety standards at the base. Interested contractors must submit their proposals by May 7, 2025, and are encouraged to attend a site visit on April 24, 2025, with further details available through the provided contacts, Gregory Graham and Alicia Scott, at the U.S. Army Corps of Engineers.
FA462525R0004, Whiteman AFB Temporary Lodging Facilities Roofing Replacement
Buyer not available
The Department of Defense, through the Department of the Air Force, is soliciting bids for the roofing replacement of Temporary Lodging Facilities (TLFs) at Whiteman Air Force Base in Missouri, under solicitation number FA462525R0004. The project entails the comprehensive replacement of approximately 27,882 square feet of roofing across six buildings, including the removal of existing roofing materials and structural components, while adhering to strict compliance with federal regulations regarding safety and environmental standards. This initiative is crucial for maintaining adequate housing for military personnel and their families, ensuring operational readiness at the base. Interested contractors must submit sealed bids by April 25, 2025, at 12:00 PM, and are encouraged to contact Tariq Abdullah at tariq.abdullah.1@us.af.mil or Caleb Kirchhoff at caleb.kirchhoff@us.af.mil for further inquiries.
138 FW Repair Central and South Base Primary Electrical
Buyer not available
The Department of Defense, specifically the Department of the Army, is soliciting bids for the Repair Central and South Base Primary Electrical project at the Tulsa Air National Guard Base in Oklahoma. This project involves the replacement of the underground electric distribution system serving various facilities, with a focus on ensuring compliance with local, state, and federal regulations while modernizing essential infrastructure. The contract is exclusively set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB), with an estimated value between $1 million and $5 million, and funding is anticipated to be available prior to the award. Interested bidders must attend a pre-bid conference on April 10, 2025, and submit their bids by May 5, 2025, with inquiries directed to Joshua Kingori at 138.FW.MSC@us.af.mil or by phone at 918-833-7305.
Commerical Electrical Work at the Mike Monroney Aeronautical Center (MMAC), Oklahoma City, OK
Buyer not available
The Department of Transportation, specifically the Federal Aviation Administration (FAA), is seeking qualified contractors for commercial electrical work at the Mike Monroney Aeronautical Center (MMAC) in Oklahoma City, OK. The project involves upgrading the electrical main service equipment, including the replacement of switchgear and motor control centers, with a construction magnitude estimated between $1 million and $5 million. This work is critical for maintaining the functionality of the Thomas P. Stafford building, which serves various administrative and training purposes. Interested vendors must submit their statements of interest and capabilities by 3:00 p.m. CST on April 11, 2025, to the FAA Contracting Office via email, with the primary contact being Neil Amaral at neil.s.amaral@faa.gov.