Paving Replacement Project - World Trade Land Port of Entry
ID: 47PH0425R0010Type: Solicitation
Overview

Buyer

GENERAL SERVICES ADMINISTRATIONPUBLIC BUILDINGS SERVICEPBS R7 NON-PROSPECTUS - BORDERFORT WORTH, TX, 76102, USA

NAICS

Highway, Street, and Bridge Construction (237310)

PSC

REPAIR OR ALTERATION OF HIGHWAYS/ROADS/STREETS/BRIDGES/RAILWAYS (Z2LB)

Set Aside

Total Small Business Set-Aside (FAR 19.5) (SBA)
Timeline
  1. 1
    Posted Jan 17, 2025, 12:00 AM UTC
  2. 2
    Updated Feb 14, 2025, 12:00 AM UTC
  3. 3
    Due Feb 28, 2025, 10:00 PM UTC
Description

The General Services Administration (GSA) is soliciting proposals for a paving replacement project at the World Trade Land Port of Entry in Laredo, Texas. The project involves replacing approximately 20,169 square feet of pavement, with two optional areas totaling an additional 12,673 square feet, and is set aside for small businesses under the Total Small Business Set-Aside program. This initiative is crucial for maintaining infrastructure that supports efficient traffic flow and border security operations, reflecting the government's commitment to enhancing public works at critical entry points. Interested contractors must submit their proposals electronically by February 28, 2025, and can direct inquiries to Rosalva Ramos at rosalva.ramos@gsa.gov or by phone at 956-454-5641.

Point(s) of Contact
Files
Title
Posted
Feb 14, 2025, 10:05 PM UTC
The document outlines Amendment No. 0001 for Solicitation 47PH0425R0010, concerning the Paving Replacement Project at the World Trade LPOE in Laredo, Texas. This amendment serves to acknowledge a Request for Information (RFI) Log dated February 14, 2025, and extends the proposal submission deadline to February 28, 2025. Key details include the conditions under which offers must acknowledge receipt of the amendment and the procedures for submitting acknowledgment or changes to existing offers. The RFI Log contains a series of questions from contractors regarding project specifications, requirements for past performance, security clearances, and concrete material specifications, along with the corresponding answers provided by the contracting officer. Notable topics involve acceptable past performance evidence, details on project staffing requirements, the necessity for specific materials like LEC concrete, and the implications of construction scheduling around LPOE operating hours. The document's intent is to clarify amendments and answered inquiries to facilitate prospective bidders in preparing competitive and compliant proposals. The amendment also reinforces that all other terms and conditions from the original solicitation remain unchanged.
Feb 14, 2025, 10:05 PM UTC
The solicitation issued by the General Services Administration (GSA) pertains to a paving replacement project at the World Trade Land Port of Entry in Laredo, Texas. The proposal requests contractors to replace approximately 20,169 square feet of pavement, with two optional replacement areas of 6,282 and 6,391 square feet respectively. Interested offerors must complete the attached Standard Form 1442, providing a total price proposal, a breakdown using Construction Specifications Institute (CSI) divisions, and a technical proposal by the deadline of February 18, 2025. The document outlines mandatory requirements such as performance and payment bonds, adherence to GSA facility standards, and reserve timeframes for government acceptance of offers. It emphasizes that proposals must be submitted via email to the designated contracting officer and includes various documents, including certifications and performance questionnaires. This solicitation reflects the government’s commitment to maintaining and improving infrastructure while ensuring compliance with federal acquisition regulations.
Feb 14, 2025, 10:05 PM UTC
The GSA Solicitation No. 47PH0425R0010 outlines essential Offeror Representations and Certifications necessary for bidders in federal contracts, particularly focusing on highway, street, and bridge construction. The solicitation details the applicable North American Industry Classification System (NAICS) code, and specific small business size standards based on average annual receipts and employee count, emphasizing inclusivity for small and disadvantaged businesses. The document specifies numerous representations and certifications needed within the System for Award Management (SAM), encompassing various FAR clauses that address factors like price determination, tax identification, and compliance with employment regulations, among others. Offerors must declare their compliance related to telecommunications security, supply chain integrity, and responsibility matters, ensuring they do not use prohibited equipment or services. Additionally, it addresses the implications of violating arms control treaties and the importance of maintaining responsible business practices. Overall, this solicitation framework not only adheres to legal procurement standards but also aims to foster transparency, accountability, and equitable opportunities in government contracting.
Feb 14, 2025, 10:05 PM UTC
The PBS Past Performance Questionnaire is designed for evaluating contractor performance in federal projects. It systematically collects information regarding the contractor's work, including basic details such as firm information, project complexity, contract specifics, and a description of the work performed. The document requests ratings on several criteria, including quality, schedule compliance, customer satisfaction, management effectiveness, financial management, safety/security, and sustainability. Each section includes rating definitions from Exceptional (E) to Unsatisfactory (U), facilitating structured feedback from clients. Completion instructions indicate that clients should directly submit their assessments to the contractor, who will include them in proposals for future work. The questionnaire aims to not only evaluate past performance but also inform future contracting decisions. A summary and comments section allows for additional insights that may highlight key strengths or weaknesses, indicating either the potential for future collaboration or concerns regarding contractor reliability. Overall, the document emphasizes the importance of past performance as a predictor of future success in government contracting.
Feb 14, 2025, 10:05 PM UTC
The document is a Contractor’s Qualifications and Financial Information form used by the U.S. General Services Administration (GSA) for assessing contractors seeking to obtain federal contracts or grants. It requires detailed information regarding the organization, including its name, type, tax identification, business history, and the nature of products or services offered. Additionally, it gathers financial data such as assets, liabilities, income statements, and any outstanding government debts or claims. The form is structured into sections addressing general information, financial obligations to the government, prepared financial statements, banking and finance company details, principal suppliers, construction/service contracts, and crucial remarks about the company's financial health and operations. The intent is to ascertain the financial responsibility and viability of contractors prior to awarding contracts. This rigorous documentation ensures compliance with federal guidelines and evaluates potential risks, thereby facilitating informed decision-making in federal procurement processes. Overall, the form serves as a critical tool in the federal grant and contracting landscape.
Feb 14, 2025, 10:05 PM UTC
The Vendor Fitness Determination Training Manual outlines the procedures and guidelines for conducting background investigations for GSA contractors as mandated by Homeland Security Presidential Directive 12 (HSPD-12). The manual provides a comprehensive framework, detailing the types of contractors requiring investigations, the process for fitness determinations, and the roles of officials and applicants. It distinguishes between long-term and short-term contractors, clarifies who does not require a background check, and explains the Special Agreement Check (SAC) procedures. Key sections include investigations types (Tier 1, 2, and 4), an overview of documentation needed for submissions, and specific instructions for completing the Contractor Information Worksheet (CIW) and other forms. It emphasizes the importance of accurate completion of forms to avoid delays in the investigation process and ensures applicants receive either a favorable Enter-on-Duty (EOD) determination or insights on any unfit determinations. This manual serves as a critical resource for maintaining security within federal facilities by ensuring thorough vetting of contractors who require physical and IT access, thereby safeguarding federal operations and information systems from potential threats or vulnerabilities.
Feb 14, 2025, 10:05 PM UTC
The proposal summary outlines the Paving Replacement Project at the World Trade Land Port of Entry in Laredo, referenced under RFP Number 47PH0425R0010. The document categorizes project costs across various construction divisions—such as existing conditions, concrete, masonry, metals, and more—although specific costs for materials, labor, and equipment are absent, likely indicating an incomplete or placeholder document ready for further detailing. Each division is essential for the comprehensive execution of the paving project, which includes tasks relevant to infrastructure improvements. General requirements and conditions also appear, yet they also lack specific information. This document serves as a foundational outline for contractors to prepare detailed bids for government-funded construction projects adhering to federal standards. Ultimately, it highlights the meticulous planning needed for public works, emphasizing transparency, accountability, and adherence to specified regulations in government RFPs.
Feb 14, 2025, 10:05 PM UTC
The Laredo WTB Limited Prospectus Paving project aims to replace damaged pavement at the Laredo Port of Entry, ensuring efficient traffic flow in high-traffic areas. Operating hours for the facility run from 7:00 AM to 12:00 AM, with significant work planned during these hours, requiring prior notification to the Project Manager. A pre-proposal meeting will address project scope and guidelines, adhering to COVID-19 protocols. The contractor will manage all materials, labor, and safety measures over a 365-day project duration, including time for security clearances and material orders. A notice to proceed must be issued by the Contracting Officer prior to work commencement. The contractor is expected to provide a detailed construction schedule, maintain a clean job site, and safeguard existing structures throughout the project’s progress. Additional requirements include waste management plans and sustainability measures, such as recycling and waste diversion. Liquidated damages apply for any delays in completion. The project emphasizes safety, compliance with regulations, and effective coordination among contractors and government representatives, showcasing the federal commitment to infrastructure improvement and traffic management at border entries.
Feb 14, 2025, 10:05 PM UTC
The Geotechnical Engineering Study conducted by Raba Kistner, Inc. for proposed roadway improvements at the World Trade Bridge Port of Entry in Laredo, Texas, outlines subsurface conditions and provides pavement design recommendations. The study was initiated following the client’s authorization in December 2022 and included four borings, which revealed layered sandy silt, clay soils, and a lack of observed groundwater. The roadway, measuring approximately 1,000 feet, is designed to accommodate significant vehicular traffic over a 20-year period, with specific vehicle classifications and expected Equivalent Single Axle Loads (ESALs) detailed. Recommendations address subgrade conditions, sulfate corrosion potential, and drainage considerations vital to long-term pavement performance. The study presents rigid pavement design options for differing traffic loads and emphasizes the importance of proper subgrade preparation, moisture control, and construction observation to mitigate variations in subsurface conditions. The document serves as a guide for future construction and adherence to Texas Department of Transportation standards, underlining critical environmental controls and budget planning for construction testing and materials observation. Overall, the study is essential in facilitating compliance and ensuring structural integrity for ongoing infrastructure development in the region.
Feb 14, 2025, 10:05 PM UTC
Feb 14, 2025, 10:05 PM UTC
Feb 14, 2025, 10:05 PM UTC
Feb 14, 2025, 10:05 PM UTC
The "World Trade Bridge Land Port of Entry Improvements" project, managed by the General Services Administration (GSA), encompasses significant upgrades at the U.S. Land Port of Entry in Laredo, Texas. Scheduled for completion in fiscal year 2021, this initiative involves removing and replacing existing concrete pavement, particularly around the primary inspection booths and alongside newly installed non-intrusive inspection equipment. The project includes specific traffic control measures and two additive alternates for additional paving areas totaling approximately 6,282 and 6,391 square feet. The construction drawings, prepared by Cushing Terrell, detail various phases of demolition and paving plans, traffic control measures, and necessary civil details compliant with Texas Department of Transportation specifications. A comprehensive traffic control plan is imperative to ensure safe operations during construction, with provisions for revising phase orders based on site conditions. This undertaking illustrates the federal government's commitment to enhancing border security infrastructure while facilitating efficient trade and travel across the southern border, aligning with broader objectives of modernization and operational effectiveness at critical entry points.
Feb 14, 2025, 10:05 PM UTC
The PBS P100 document outlines mandatory facilities standards for the Public Buildings Service (PBS) of the U.S. General Services Administration (GSA). It serves as a guideline for the design, construction, and maintenance of federal buildings, applicable across various project types funded by GSA. The standards emphasize performance-based requirements, integrating federal laws, environmental protection, and accessibility considerations. The document is structured into chapters addressing general requirements, urban development, architecture, engineering disciplines, and fire protection, among others. Key areas include compliance with national codes, energy efficiency, safety protocols, state and local regulations, and incorporation of sustainability measures. The P100 also mandates consultation with local governments to ensure design compatibility with community standards. The purpose of the P100 is to unify building practices and optimize facility operations, ensuring compliance with legal and environmental standards while enhancing safety and accessibility. This document plays a key role in shaping government contracts, grants, and requests for proposals (RFPs), signifying its importance in federal funding and real estate management.
Feb 14, 2025, 10:05 PM UTC
The PBS CAD Standards documentation outlines essential guidelines for architects and engineers (A/Es) preparing Computer-Aided Design (CAD) submissions for the General Services Administration (GSA). Key points include adherence to the United States National CAD Standard (NCS) Version 6, the "no error" requirement for DWG file submissions, and specific document components required for each submission. A/Es are mandated to submit an accompanying signed cover letter and a completed NCS Statement of Substantial Conformance. Compliance with GSA’s guidelines ensures that all drawings are accurate and functional, highlighting the significance of digital file management, including labeling and presentation. The document also includes naming conventions for files, drawing sheets, and model files, emphasizing GSA's ownership of all digital outputs. The standards are designed to facilitate efficient communication and ensure reliability in the design and construction process, underscoring the government's commitment to maintain high-quality standards in architectural projects. Non-compliance can result in contract repercussions, reinforcing the importance of thorough adherence to these guidelines in the context of federal contracts and grants.
Feb 14, 2025, 10:05 PM UTC
The document outlines General Decision Number TX20250003, effective January 3, 2025, regarding minimum wage rates for heavy and highway construction projects in Cameron, Hidalgo, and Webb Counties, Texas. It details wage requirements under the Davis-Bacon Act, particularly highlighting the applicability of Executive Orders 14026 and 13658. Contracts initiated after January 30, 2022, must pay workers a minimum wage of $17.75 per hour, while those awarded between January 1, 2015, and January 29, 2022, have a lower rate of $13.30 if not extended post-January 2022. The wage determination provides specific rates for various worker classifications, including cement masons, laborers, equipment operators, truck drivers, and welders, with notes on fringe benefits and potential higher wages under executive orders. Additionally, the document outlines the process for wage determination appeals, directing inquiries to the U.S. Department of Labor. This decision reflects government efforts to ensure fair compensation for laborers engaged in federally funded construction projects while promoting compliance with labor standards.
Feb 14, 2025, 10:05 PM UTC
The document outlines a federal construction contract for the Paving Replacement Project at the World Trade Land Port of Entry in Laredo, Texas. The primary focus is on the contractor's responsibilities, which include providing all required labor, materials, and equipment, with a performance period of 365 days post-Notice to Proceed. It specifies operating conditions, such as working primarily during business hours with project-hour notifications required. Key contractual elements include pricing structures, insurance requirements, liquidated damages for delays, and compliance with the Buy American Act. Additional provisions encompass procedures for submitting documents, handling changes or modifications, and maintaining contractor responsibilities, emphasizing adherence to safety and regulatory standards. The inclusion of various clauses ensures that both the U.S. General Services Administration and the contractor understand their obligations and rights under the contract. Overall, the document serves as a comprehensive guideline for managing construction operations at a federal facility, highlighting the government's focus on maintaining high standards in public works projects.
Feb 14, 2025, 10:05 PM UTC
The GSA Solicitation No. 47PH0425R0010 outlines the requirements for a construction contract to replace paving at the World Trade Land Port of Entry in Laredo, Texas. This project is set aside for small businesses, with an estimated cost between $1,000,000 and $5,000,000. The document includes critical sections on general information, proposal contents, provisions, and evaluation criteria. Offerors must submit both price and technical proposals, demonstrating past experience, performance, and a detailed project approach that meets sustainability goals, including diverting 50% of construction waste. Key dates include a pre-proposal conference on January 29, 2025, and a proposal submission deadline of February 18, 2025. Offers must be received electronically. Evaluation will consider both price and non-price factors, with past experience and technical approach being crucial. Contracting details also highlight bonding requirements and stipulations ensuring equal opportunity in hiring practices. Overall, the solicitation exemplifies the government's commitment to engaging small businesses while ensuring compliance with federal procurement regulations and environmental standards.
Lifecycle
Title
Type
Solicitation
Presolicitation
Similar Opportunities
CONSTRUCTION SERVICES FOR MULITPLE NEW LAND PORT OF ENTRY
Buyer not available
The General Services Administration (GSA) is seeking qualified construction contractors to provide services for multiple new Land Ports of Entry (LPOE) projects located in Vermont and Maine. The projects involve the renovation and modernization of existing facilities at five specific locations: Alburg Springs, Beebe Plain, Calais Ferry Point, Norton, and Richford, with the aim of enhancing security, improving traffic flow, and ensuring compliance with Customs and Border Protection requirements. The expected construction durations range from 12 to 36 months, with estimated project costs varying from $5 million to $50 million depending on the location. Interested firms must demonstrate relevant experience and meet specific criteria, with submissions due by April 21, 2025. For further inquiries, interested parties can contact Carolyn Weekes at carolyn.weekes@gsa.gov or Michele Valenza at michele.valenza@gsa.gov.
General Services Administration (GSA) seeks to lease the following space: Laredo, Texas
Buyer not available
The General Services Administration (GSA) is seeking to lease office space in Laredo, Texas, through its Public Buildings Service. The procurement aims to secure a suitable location for federal operations, emphasizing the need for compliance with specific leasing requirements under the NAICS code 531190, which pertains to lessors of other real estate property. This opportunity is critical for ensuring that government agencies have access to functional and efficient office environments to support their missions. Interested parties can reach out to Michael Noye at michael.noye@gsa.gov or 817-201-9326, or Bryant Crot at bryant.crot@gsa.gov or 817-850-8234 for further details.
Land Port of Entry Facility Expansion and Modernization Trout River, New York
Buyer not available
The General Services Administration (GSA) is seeking a qualified General Contractor (GC) for the expansion and modernization of the U.S. Land Port of Entry (LPOE) located in Trout River, New York. The project aims to enhance the existing facility to meet updated Department of Homeland Security requirements, including the construction of new vehicle inspection facilities and the renovation of the historic Headhouse. This procurement is significant as it will support the GSA's sustainability objectives, including achieving LEED Gold certification and utilizing funding from the Inflation Reduction Act for high-performance green building measures. The anticipated contract, valued between $20 million and $30 million, is expected to be awarded in Spring 2025, with a performance period of approximately 27 months. Interested contractors must ensure active registration in the System for Award Management (www.sam.gov) at the time of offer submission.
General Services Administration (GSA) seeks to lease the following space: Pearsall, Texas
Buyer not available
The General Services Administration (GSA) is seeking to lease office space in Pearsall, Texas, specifically within the city limits. The requirements include a minimum and maximum space of 3,892 square feet, with occupancy on the first floor and 24/7 HVAC for a server room, as the space will be utilized by a customer-facing agency. This procurement is crucial for ensuring that the GSA meets its operational needs while adhering to government standards for fire safety, accessibility, and sustainability. Interested parties must submit their expressions of interest by April 21, 2025, and can contact Marc Hortinela at marcryan.hortinela@gsa.gov or Cynthia Kirby at cynthia.kirby@gsa.gov for further information.
General Services Administration (GSA) seeks to lease the following space: San Antonio, Texas
Buyer not available
The General Services Administration (GSA) is seeking to lease office space in San Antonio, Texas, with specific requirements for the location and facilities. The GSA requires a minimum of 4,216 square feet of office space, which must comply with government standards for fire safety, accessibility, seismic, and sustainability, and must not be located in a floodplain. This procurement is crucial as the U.S. Government is considering alternative spaces due to the expiration of its current lease, taking into account factors such as cost and the feasibility of relocation. Interested parties should submit their expressions of interest by April 7, 2025, and can contact Marc Hortinela at marcryan.hortinela@gsa.gov or Matthew Van Allen at matthew.vanallen@gsa.gov for further information.
Design-Build for the Tunnel Barrier Project at the Giaimo Federal Building, New Haven CT
Buyer not available
The General Services Administration (GSA) is seeking qualified small businesses to participate in a Sources Sought notice for the Design-Build for the Tunnel Barrier Project at the Giaimo Federal Building in New Haven, Connecticut. The project involves the demolition and replacement of existing Active Vehicle Barriers (AVBs) at two tunnel locations, including the integration of controls and a ballistic-rated guard booth, with an estimated construction value between $1 million and $5 million. This procurement is crucial for enhancing security measures at the facility, and interested parties are encouraged to submit a capabilities package by April 18, 2025, to the primary contacts Adam Katzman and Stephanie Klein via email. The GSA aims to assess the availability of qualified small business sources, including those certified under various SBA programs, to determine the appropriate acquisition strategy.
Dunseith North Dakota LPOE Emergency Generator Replacement
Buyer not available
The General Services Administration (GSA) is soliciting proposals for the replacement of an emergency generator at the Dunseith Land Port of Entry (LPOE) in North Dakota. The project aims to install a new propane-capable generator to replace the existing non-functional 25KW unit, ensuring operational resilience at this critical border entry point. This procurement is a total small business set-aside, with an estimated construction cost between $25,000 and $100,000, and requires completion within 70 calendar days from the notice to proceed. Interested contractors must submit sealed bids by April 9, 2025, and can obtain solicitation documents at no charge from the System for Award Management website. For further inquiries, contact Cody Lee at cody.lee@gsa.gov or Jesse Johnson at jesse.johnson@gsa.gov.
Coburn Gore LPOE CMc Pre-Solicitation
Buyer not available
The General Services Administration (GSA) is seeking qualified contractors for the construction of a new Land Port of Entry (LPOE) in Coburn Gore, Maine, utilizing the Construction Manager as Constructor (CMc) delivery method. The project aims to modernize and expand the existing LPOE, which is listed on the National Register of Historic Places, to enhance operational capabilities, improve infrastructure, and support U.S. Customs and Border Protection's mission while maintaining the site's historic character. The estimated construction cost ranges from $80 million to $100 million, with design phase services expected to commence in Summer/Fall 2025 and construction anticipated to begin in Summer 2026. Interested parties should contact James M. Adamo at james.adamo@gsa.gov or Caitlyn Egan at caitlyn.egan@gsa.gov for further information and must register on SAM.gov to receive updates and access the solicitation, which will be available around April 11, 2025.
Garmatz Courthouse Windows Replacement
Buyer not available
The General Services Administration (GSA) is seeking qualified contractors for the Garmatz Courthouse Windows Replacement project in Baltimore, Maryland. This Sources Sought Notice aims to gather information on small business contractors capable of performing modernization and repair work, specifically the replacement of deteriorating original windows and concrete sidewalks at the Edward A. Garmatz U.S. District Courthouse. The project is significant for enhancing the building's energy efficiency and addressing current issues such as air leakage and inadequate temperature control, with an estimated construction cost ranging from $10 million to $20 million. Interested contractors must submit their responses by April 18, 2025, with the phased solicitation process expected to begin in Spring 2025 and conclude with contract awards in late 2025 or early 2026. For further inquiries, contact Stephen Boettcher at stephen.boettcher@gsa.gov or call 215-687-5870.
Tactical Infrastructure (TI) Maintenance DRT, LRT, RGV
Buyer not available
The Department of Homeland Security, specifically the U.S. Customs and Border Protection (CBP), is seeking qualified contractors for a Competitive 8(a) Request for Proposals (RFP) to provide maintenance and repair services for Tactical Infrastructure (TI) assets along the U.S./Mexico border in the Rio Grande Valley, Laredo, and Del Rio/Big Bend South sectors. The procurement encompasses a range of services including maintenance of roads, bridges, fences, vegetation control, debris removal, border lighting, and drainage systems, requiring contractors to supply all necessary personnel, materials, and equipment. This initiative is critical for maintaining border security infrastructure, and interested 8(a) contractors must attend mandatory site visits scheduled for April 15-17, 2025, to gather essential information for their proposals. RSVPs for the site visits are due by April 7, 2025, and inquiries should be directed to Allison Baker at allison.e.baker@cbp.dhs.gov or Donna McMullen at donna.r.mcmullen@cbp.dhs.gov.