Z2DA-- Repair Hillside Slip 540-23-104 Clarksburg VAMC
ID: 36C24524B0023Type: Solicitation
Overview

Buyer

VETERANS AFFAIRS, DEPARTMENT OFVETERANS AFFAIRS, DEPARTMENT OF245-NETWORK CONTRACT OFFICE 5 (36C245)LINTHICUM, MD, 21090, USA

NAICS

Commercial and Institutional Building Construction (236220)

PSC

REPAIR OR ALTERATION OF HOSPITALS AND INFIRMARIES (Z2DA)
Timeline
  1. 1
    Posted Nov 27, 2024, 12:00 AM UTC
  2. 2
    Updated Dec 31, 2024, 12:00 AM UTC
  3. 3
    Due Jan 7, 2025, 8:00 PM UTC
Description

The Department of Veterans Affairs is soliciting bids for the "Repair Hillside Slip" project (Project Number 540-23-104) at the Louis A. Johnson VA Medical Center in Clarksburg, West Virginia. The project aims to stabilize a hillside slip by installing Geopier SRT Plate Piles, with a construction timeline of 90 days following the Notice to Proceed. This initiative is critical for ensuring the safety and accessibility of the medical facility, which serves veterans, and emphasizes adherence to strict safety, health, and environmental protocols throughout the construction process. Bids are due on January 7, 2025, with a public bid opening scheduled for the same day; interested contractors should contact Contract Specialist Aaron Z Morrison at Aaron.Morrison@va.gov for further details.

Point(s) of Contact
Aaron Z MorrisonContract Specialist
Aaron.Morrison@va.gov
Files
Title
Posted
Dec 31, 2024, 5:05 PM UTC
The Department of Veterans Affairs (VA) has issued a solicitation for a construction project titled "Repair Hillside Slip," designated as Project Number 540-23-104. This project entails designing, furnishing, and installing Geopier SRT Plate Piles at the VA Medical Center in Clarksburg, WV, to stabilize a hillside slip. The contractor is required to complete the work within 90 days of receiving the Notice to Proceed while adhering to strict safety, health, and infection control measures due to the proximity to an active medical facility. The solicitation encourages bidders to inspect the site and emphasizes that the project is a 100% Service-Disabled Veteran Owned Small Business Set-Aside. Bids will be due on January 7, 2025, and a public bid opening will occur that same day. Contractors must acquire all necessary licenses and obtain permits related to the work, ensuring compliance with state and local regulations. Additionally, all work must be completed in accordance with detailed technical specifications and safety protocols to protect both the site and surrounding operations.
Oct 31, 2024, 3:48 PM UTC
The Department of Veterans Affairs intends to issue an Invitation for Bids (IFB) for the "Repair Hillside Slip" project at the Louis A. Johnson VA Medical Center in Clarksburg, WV. This initiative requires contractors to provide all necessary labor, materials, and supervision for the construction services over a performance period of 90 days. The project, estimated between $250,000 and $500,000, is set aside for Service Disabled Veteran Owned Small Businesses (SDVOSB), with a NAICS Code of 236220. Interested bidders must register in the System for Award Management (SAM) and obtain the solicitation information solely through the SAM website. A pre-bid site visit is scheduled, with details to be announced. All inquiries must be submitted in writing to the designated Contracting Officer, Aaron Morrison. The contract will be awarded based on the availability of funds, highlighting the government's preference for veteran participation in federal contracts. The notice emphasizes the importance of verifying updates online, reiterating that the government is not liable for missed notifications.
Dec 31, 2024, 5:05 PM UTC
This document is an amendment to the solicitation concerning the "Repair Hillside Slip" project (Project Number 540-23-104) being administered by the Department of Veterans Affairs, Network Contracting Office 5. The amendment addresses responses to Requests for Information (RFIs) submitted by December 11, 2024. It includes the updated Statement of Work (SOW), specifications, diagrams, a Full Geo Tech Report, and a Brand Justification document. The public bid opening is scheduled for January 7, 2025, at 3 PM in Clarksburg, WV, with a reminder that electronic submissions will not be accepted. The amendment urges bidders to ensure they are aware of any amendments via the SAMS website and specifies that pricing should use the bid schedule in the solicitation. While this document details necessary amendments and responses to inquiries, it confirms that all other conditions of the solicitation remain unchanged. The amendment reflects the government’s commitment to transparency and thoroughness in the bidding process, facilitating compliance with procurement protocols.
Dec 31, 2024, 5:05 PM UTC
The VHA Infection Control Risk Assessment (ICRA) template serves as a guideline for assessing infection control measures during construction, renovation, and maintenance activities at VA facilities. It outlines a systematic approach to categorize activities and evaluate patient risk levels to determine necessary infection precautions. Users complete four primary steps to identify activity type, affected areas, patient risk categories, and required infection control precautions before project initiation. The template categorizes activities into four levels—A through D—based on duration, type of work, and patient exposure risks, with corresponding infection prevention and control levels ranging from I to IV. The document emphasizes the importance of conducting activities without generating dust, implementing measures to control airborne contaminants, and maintaining safe interactions with the HVAC and potable water systems. Lastly, a permit form for specific projects is mandated for higher risk categories, ensuring the implementation of the outlined infection control measures. This framework reflects the VA's commitment to maintaining safe environments for patients and staff during facility upgrade processes, aligning with regulatory standards in health care construction projects.
Dec 31, 2024, 5:05 PM UTC
The VHA Pre-Construction Risk Assessment (PCRA) template serves as a crucial guideline for evaluating risks associated with construction, renovation, and maintenance activities within healthcare facilities. It outlines minimum requirements for categorizing activities based on their potential safety risks to patients, employees, and contractors. Each activity must include comprehensive communication and coordination plans, starting from the planning phase, to ensure that all affected areas are considered. The PCRA specifically focuses on non-infection-related safety, requiring collaboration with the VHA Infection Control Risk Assessment (ICRA) when necessary. The document also details control measures categorized by activity type: small-scale, large-scale, and inspection/upkeep, enhancing safety through specific protocols such as regular site inspections, hazard communication, and detailed planning for adjacent affected areas. Control measures must be implemented before work begins and maintained until completion. The example project highlighted in the PCRA is a small-scale initiative involving hillside stabilization adjacent to a parking garage, presenting low risks but requiring careful dust and noise management due to proximity to occupied areas. Overall, the PCRA reinforces the commitment to maintaining safe environments during construction activities in VA facilities.
The document presents a Brand Name Justification related to procurement for construction work at the Clarksburg VA Medical Center. It establishes that the Geopier SRT Pile system is specifically required due to its unique features, which are crucial for the project’s successful completion. Compliance with Federal Acquisition Regulation (FAR) and Veterans Affairs Acquisition Regulation (VAAR) specifies that market research confirmed no alternate products sufficiently meet the agency's needs. The justification highlights that the general contractor must possess expertise in this proprietary system, which is developed by GeoPier Company and manufactured in the USA. The document also includes approval signatures from the Contracting Officer and Contracting Officer Representative, affirming the necessity of using the specified brand for project execution. This justification reinforces the government's objective to ensure effective project delivery by relying on trusted and qualified products while addressing regulatory requirements related to federal RFPs and procurement processes.
Dec 31, 2024, 5:05 PM UTC
The document appears to be a corrupted data entry that lacks coherent information related to any specific government request for proposal (RFP) or grant. However, inferred from the initial segments, it seems to involve data or entries related to federal or local government projects, possibly indicating project specifications, guidelines, or budget information. Common elements found in such documents usually include project objectives, budget considerations, evaluation criteria, compliance requirements, and deadlines for submissions. Given the fragmented nature and encoded text, it may contain metadata or formatted strings, which could be typical for RFP submissions or grant applications. These documents are crucial as they guide contractors and agencies in fulfilling governmental obligations while also ensuring accountability and proper resource allocation. As an analytical evaluation, this document could potentially serve various administrative functions but does not present clear or actionable information due to its corrupted state.
Dec 31, 2024, 5:05 PM UTC
The document comprises responses to pre-bid RFIs for the Repair Hillside Slip Project #540-23-104, issued by the Department of Veterans Affairs (VA). Key concerns addressed include the necessity of compaction benching, the requirement for embedding plate piles into weathered rock, and protocols for photography and inspections. The VA confirms that compaction benching is mandatory, and plate piles must have a minimum 2-foot embedment, with predrilling required if conditions dictate. The document clarifies permitting requirements, emphasizing adherence to WVDOH guidelines, and outlines that commercial photography is not mandatory but significant documentation is expected. The document also addresses staffing requirements, confirming that the superintendent may serve as Safety and Health Officer (SSHO) and that additional permits are necessary for environmental compliance. Questions regarding the engagement of Ground Penetrating Radar, potential rock encounters during excavation, and ongoing site stability during construction were also clarified, indicating that the plans are robust enough for anticipated conditions. The document concludes with references to timelines, emphasizing that requests for extensions to the 90-day period of performance will be evaluated post-award, showcasing a commitment to ensuring the project adheres to regulatory and safety standards throughout the construction process.
Dec 31, 2024, 5:05 PM UTC
Dec 31, 2024, 5:05 PM UTC
The "Repair Hillside Slip" project at the LAJVAMC Exterior Campus aims to implement Geopier SRT Plate Pile installation as part of a hillside stabilization effort. This 90-day construction project involves site preparation, demolition, and installation work to mitigate a hillside slip adjacent to the active VA Medical Center in Clarksburg, WV. Bidders must develop a comprehensive mobilization plan, secure permits, and adhere to infection prevention measures throughout the project's duration. The contractor is responsible for all aspects of the construction, including site-specific traffic control and compliance with all VA regulations and local codes. Key elements include maintaining patient safety, minimizing service disruptions, and ensuring environmental protection and proper waste disposal. Additionally, coordination with the VA’s Contracting Officer’s Representative (COR) is essential for project management. The project emphasizes adherence to safety protocols and efficient operations to uphold ongoing medical facility functions.
Dec 31, 2024, 5:05 PM UTC
The Hillside Slip Project involves essential repairs and management at the Louis A. Johnson Veterans Affairs Medical Center in Clarksburg, WV. The project focuses on addressing a landslide and improving the site's stability through a series of engineering interventions, including geotechnical assessment and erosion control. Key contractors involved include Integrity Federal Services (civil engineering), ECS Mid-Atlantic (geotechnical engineering), and CB Design Group (architectural management). The bid documents outline the project’s requirements: comprehensive geotechnical analysis, erosion and sediment control measures, and construction laydown and traffic control plans. It emphasizes the necessity of securing proper permits from the West Virginia Department of Transportation and coordinating water runoff strategies to minimize environmental impact. The construction will comply with federal and state regulations, ensuring safety and sustainability throughout the process. Overall, the project aims to enhance the infrastructure while safeguarding the health of the environment and the public, reflecting the VA's ongoing commitment to maintaining its facilities and supporting veterans effectively.
Dec 31, 2024, 5:05 PM UTC
The Hillside Slip Project at the Louis A. Johnson VA Medical Center in Clarksburg, WV, is focused on addressing landslide risk and improving site stability. The project involves a comprehensive plan comprising a series of bid documents detailing the necessary construction, civil and geotechnical engineering efforts. Key elements include a construction laydown plan, a traffic control plan, and erosion and sediment control measures that adhere to West Virginia regulations. Consultants such as Integrity Federal Services and ECS, Mid-Atlantic are engaged for civil and geotechnical engineering services, respectively. The project emphasizes compliance with erosion control best practices, sediment management during construction, and the need for environmental protection measures. Various construction techniques, including subsurface drainage systems and proper soil stabilization methods, are outlined to manage runoff and ensure site safety. The document serves as a framework for contractors, guiding them through the regulatory processes required by state and federal standards. It underscores the VA's commitment to maintaining safe, accessible healthcare facilities for veterans while ensuring ecological compliance throughout the construction process.
Dec 31, 2024, 5:05 PM UTC
The document outlines the bid submission specifications for the "Repair Hillside Slip" project at the Louis A. Johnson VA Medical Center (VA Project #540-23-104). Prepared by CB Design Group, the bid serves as an invitation for contractors to carry out specific construction work with a construction duration set for 90 days following the Notice to Proceed. Key elements include comprehensive general and site-specific requirements, safety standards, and security protocols to protect sensitive areas. The project emphasizes the necessity for bidders to have a clear understanding of the existing site conditions, emphasizing the evaluation of subsurface materials prior to bid submission. Contractors are required to submit project schedules utilizing the Critical Path Method (CPM) and must coordinate thoroughly with the West Virginia Department of Highways (WVDOH) for traffic control plans and permits. Photographic documentation of construction progress is another crucial requirement, ensuring transparency and compliance throughout the project lifecycle. Overall, the document serves to establish a structured framework for conducting renovations while maintaining site safety, regulatory compliance, and operational continuity within the medical facility, thereby illustrating the VA's commitment to infrastructure improvement and veteran services.
The document outlines the bid specifications for the "Repair Hillside Slip" project at the Louis A. Johnson VA Medical Center in Clarksburg, WV, under VA Project #540-23-104. It covers key requirements for bidders, emphasizing that the contractor must prepare the site for construction, manage safety protocols, and adhere to the General Requirements that detail the responsibilities during the project. Bidders are urged to visit the site before submitting proposals. The scope includes general construction tasks, site mobilization plans, and obtaining necessary permits. A significant focus is placed on security protocols surrounding the project, compliance with environmental controls, and managing utilities efficiently. The contractor must also develop a detailed Project Schedule employing Critical Path Method (CPM) for scheduling and reporting purposes. The meticulous requirements reflect the government's commitment to ensuring safety, quality, and regulatory compliance throughout the construction process, while maintaining the operational integrity of the medical center. Overall, this document serves as a comprehensive guide for contractors interested in submitting bids for the project, ensuring alignment with federal and VA standards.
Dec 31, 2024, 5:05 PM UTC
The document outlines specifications for a construction project, specifically the "Repair Hillside Slip" initiative managed by Claire O'Connor, AIA. Updated as of July 24, 2024, the file includes general requirements, safety protocols, and quality control measures, segmented into categorized specifications. Key sections cover project scheduling, submittals of shop drawings, and safety plans, detailing required documents such as environmental protection plans, accident prevention plans, and testing reports that contractors must submit. It emphasizes the importance of adhering to established standards, conducting thorough inspections, and maintaining compliance with environmental regulations throughout the project's lifecycle. The structured submission register facilitates tracking of required documents, ensuring organized workflows and accountability. This initiative illustrates the federal government's emphasis on safe, quality construction practices while mitigating environmental risks, aligning with federal RFP protocols and local regulations.
Dec 31, 2024, 5:05 PM UTC
ECS Mid-Atlantic, LLC performed a subsurface exploration and geotechnical engineering analysis at the Louis A. Johnson VA Medical Center in Clarksburg, West Virginia, following a landslide in summer 2022. The exploration aimed to assess slope conditions and provide slope repair recommendations essential to stabilize the site. Two test borings were conducted to explore subsurface conditions, revealing a composition of weathered siltstone and various soil types typical of landslide-prone areas. Groundwater was observed at depths of about 20 feet. The report identifies three potential repair concepts that achieve a safety factor of 1.5: a Reinforced Soil Slope (RSS), Rock Buttress, and the Geopier SRT® system, each incorporating specific geotechnical measures such as geo-grids and structural fill materials. The analysis emphasizes the importance of careful site preparation, suitable materials, and ongoing monitoring during construction to ensure stability and avoid future landslides. Final design and construction drawings will follow separately. This report serves as a comprehensive foundation for addressing the site's geological challenges and aims to secure funding and approvals for necessary remedial actions.
Lifecycle
Title
Type
Solicitation
Presolicitation
Similar Opportunities
Z2DA--542-25-105 | Replace Pitched Roof Building 1 | NCO 4 Construction East (VA-25-00008811)
Buyer not available
The Department of Veterans Affairs is soliciting bids for the replacement of the pitched roof on Building 1 at the Coatesville Veterans Affairs Medical Center, designated as Project 542-25-105. This project involves comprehensive demolition and construction activities, including the installation of a new roofing system, flashing, gutters, and lightning protection, all while adhering to stringent safety and environmental standards. The initiative is crucial for maintaining the structural integrity of the facility, which serves veterans, and emphasizes the use of modern materials and sustainable practices. Interested contractors must submit their bids by May 20, 2025, and direct inquiries to Contract Specialist Lamar D. Thomas at lamar.thomas2@va.gov. The anticipated contract value ranges between $500,000 and $1 million, with a performance period of 160 days post-award.
Y1DA--589-703 Construct Addition and Renovate Community Living Center, Building 60 (VA-24-00028736)
Buyer not available
The Department of Veterans Affairs is seeking contractors for the construction of an addition and renovation of the Community Living Center, Building 60, under project VA-24-00028736. This procurement aims to enhance facilities for veterans, aligning with the VA's mission to improve care and living conditions. The estimated project cost is approximately $24.4 million, with bids received ranging from $18 million to nearly $20 million, emphasizing a competitive bidding process. Interested parties should contact Contract Specialist Joshua Slapnicker at joshua.slapnicker@va.gov, and note that responses to the solicitation must be submitted by the specified deadline, with all bids archived 90 days afterward.
Z1DA--Install Patient Lifts 578-15-001
Buyer not available
The Department of Veterans Affairs is soliciting proposals for the installation of patient lifts at the Edward Hines Jr. VA Hospital, identified as Project 578-15-001. This project involves the installation of approximately 60 permanent ceiling-mounted patient lifts across multiple locations within the facility, aimed at enhancing patient mobility and safety. The contractor will be responsible for providing all necessary labor, materials, and equipment to complete the installation within 432 calendar days after receiving the Notice to Proceed, with an estimated project cost between $2,000,000 and $5,000,000. Interested contractors must submit their sealed bids by April 3, 2025, at 1:00 PM CST, and are encouraged to attend a site visit scheduled for March 5, 2025. For further inquiries, contractors can contact Donita L Grace at donita.grace@va.gov.
Z2DA--Tuck Point and Seal Ambulatory Care Addition of Bldg 1 PN:589A4-23-103,
Buyer not available
The Department of Veterans Affairs is soliciting proposals for a construction contract focused on the tuckpointing and sealing of the Ambulatory Care Addition at the Harry S. Truman Medical Center in Columbia, Missouri, under Project Number 589A4-23-103. This project aims to enhance the structural integrity and safety of the facility, ensuring compliance with federal regulations and environmental standards, while prioritizing the health and safety of veterans. The contract is set aside for Service-Disabled Veteran Owned Small Businesses (SDVOSB) with a budget ranging from $1,000,000 to $2,000,000 and a performance period of 300 days post-award. Interested contractors must submit their proposals by April 4, 2025, at 2:00 PM CDT, and are encouraged to contact Contract Specialist Jeanette G Mathena at jeanette.mathena@va.gov for further information.
Z2DA--Asphalt Maintenance and Repair | 442-23-001
Buyer not available
The Department of Veterans Affairs is soliciting proposals for asphalt maintenance and repair services at the Cheyenne VA Medical Center in Wyoming, under contract number 442-23-001. The project involves aggregate base repair, concrete removal, asphalt replacement, and pavement striping, with an estimated budget between $500,000 and $1,000,000, and is exclusively set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSBs). Interested contractors must ensure compliance with federal regulations, including safety and environmental standards, and submit their proposals electronically by April 25, 2025, at 2:00 PM MDT. For further inquiries, contact Timothy Verburgt at Timothy.Verburgt@va.gov.
Y1DA-- Improve Patient Privacy 4B Project# 652-14-106
Buyer not available
The Department of Veterans Affairs is seeking qualified contractors for the "Improve Patient Privacy 4B" project at the Richmond VA Medical Center, designated as Project Number 652-14-106. This procurement involves extensive renovations to enhance patient privacy, including the construction of 21 patient rooms and supporting spaces, with a contract value estimated between $5 million and $10 million. The project is a 100% Service-Disabled Veteran-Owned Small Business (SDVOSB) set-aside, emphasizing the importance of veteran-owned enterprises in federal contracting. Interested bidders must submit their proposals by April 22, 2025, with the bid opening scheduled for April 23, 2025. For further inquiries, potential offerors can contact Contract Specialist Denise Morman at Denise.Morman@va.gov.
J044--Replace Chiller Plant Expansion Tanks | RFQ ENDS 4/5/25 | SITE VISIT
Buyer not available
The Department of Veterans Affairs is soliciting proposals for the replacement of chiller plant expansion tanks at the Huntington VA Medical Center (VAMC) in West Virginia. This project aims to enhance the operational efficiency and maintenance of the facility's cooling systems, which are critical for providing a comfortable environment for veterans receiving care. The contract is set aside for small businesses, with a total budget of $47 million, and the performance period is scheduled from April 15, 2025, to April 14, 2026. Interested vendors must submit their proposals by April 5, 2025, and can direct inquiries to Contracting Officer John Ritter at JOHN.RITTER2@VA.GOV or by phone at 843-814-0299.
Z1DA--VISN 20 General Construction MATOC Replacement Construction Services
Buyer not available
The Department of Veterans Affairs is seeking contractors for the Z1DA--VISN 20 General Construction MATOC Replacement Construction Services project, which involves the renovation of Building 20 at the Vancouver Veterans Affairs Medical Center to consolidate dental services. The project includes extensive alterations such as creating dental treatment rooms, supporting spaces, and ensuring compliance with safety protocols while maintaining operations at the medical center during construction. This initiative is crucial for modernizing healthcare facilities and enhancing service delivery to veterans. Key deadlines include a virtual pre-proposal meeting on April 17, 2025, an in-person site visit on May 1, 2025, and proposal submissions due by May 14, 2025. Interested parties should direct technical questions to Contract Officer Wendy A. Duval at Wendy.Duval@va.gov.
861CM3011: Facility Condition Assessment (FCA) Deficiencies Corrections Repairs, Mill Springs National Cemetery
Buyer not available
The Department of Veterans Affairs is soliciting proposals for a firm-fixed-price contract to address deficiencies identified in the Facility Condition Assessment (FCA) at Mill Springs National Cemetery. The project involves comprehensive renovations and repairs, including updates to the Maintenance Building, road resurfacing, and various site improvements, all aimed at enhancing the cemetery's infrastructure while ensuring compliance with local, state, and federal regulations. This procurement is exclusively set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB), with an estimated contract value between $1,000,000 and $5,000,000, and a performance period of 270 days from the notice to proceed. Interested bidders must submit sealed proposals by April 7, 2025, and can contact Clarelle Sylvain at clarelle.sylvain@va.gov for further information.
Z2DA--675-22-706A EHRM Infrastructure Upgrades Construction Viera VA Clinic
Buyer not available
The Department of Veterans Affairs is soliciting proposals for the EHRM Infrastructure Upgrades Construction project at the Viera VA Clinic in Florida, with an estimated contract value between $2 million and $5 million. This project aims to modernize the clinic's infrastructure to comply with Electronic Health Record Modernization requirements, including enhancements to telecommunication and utility systems, while ensuring minimal disruption to ongoing medical operations. The procurement is set aside for Service-Disabled Veteran-Owned Small Businesses (SDVOSB), and interested bidders must adhere to strict compliance with federal regulations, including sustainability mandates and labor standards. The deadline for submitting offers has been extended to April 17, 2025, at 10:30 AM EDT, and inquiries can be directed to Contract Specialist Sharese H McKinney at sharese.mckinney@va.gov.